The URL can be used to link to this page

3308 The Town of Tillsonburg is desirous of entering into an agreement with Gateman Milloy for the development of trailsBY-LAW NUMBER 3308 3a THI: CORPORATION OF THE TOWN OF T/LLSONBURC WHEREA,� The Town of Tillsonburg is desirous of entering into an agreement with Gateman Milloy for the development of trails. THEREFC1RE the Council of the Town of Tillsonburg enacts as follows: 1. THAT the Town of Tillsonburg enter into an agreement with Gateman Milloy for the dcv(1opnicrit of trails; 2. THAT the Mayor and Clerk be hereby authorized to execute the attached agreement marled as Schedule "A" on behalf of the Corporation of the Town of Tillsonburg at such tinic as the lease agreement, previously authorized under By -Law 3276 has been fully exec utcd. READ A FIRST AND SECOND TIME THIS 28th DAY OF February, 2008. READ A TH /10 AND FINAL TIME AND PASSED THIS 28" DAY OF February, 2008. MAYOR-Stcphcn Molnar CLERK -M- chael Graves Standard construction document des'6 ign-build stiplLilated price contract Project: THE CO=RPORATION OF THE TOWN OF TILLSONBURG COMML LAITY TRAIL DEVELOPMENT r ok16, f�? va. i Endorsed by: The Canadian Construction Association Construction �l'pecifications Canada The Royal Architectural Institute of Canada Apply a Document 14 copyright seal here. The application of the seal demonstrates the intention of the party proposing the use of this document that it be an accurate and unamended form of Document 14 — 2000 except to the extent that any alterations, additions or modifications are set forth in supplementary conditions. INSTRUCTIONS TO USERS OF DOCUMENT 14 - 2000 CCA-CSC-RAIC DOCUMENT 14 - 2000 DE'iIGN-BUILD STIPULATED PRICE CONTRACT September 2000 The Design -Build Stipulated Price Contract is developed by the Joint Design -Build Working Group comprised of representatives from: The Canadian Construction Association Construction Specifications Canada The Royal Architectural Institute of Canada This document is based on CCDC 2 — 1994 `Stipulated Price Contract' and CCAC 6 — 1994 `Canadian Standard Form of Agreement Between Client and Architect'. A number of terms in Document 14 are defined differently from other standard contract documents and, accordingly, all definitic ns should be read to properly understand the terms and conditions of this document. THE FOLLOWING ARE THE BASIC PRINCIPLES OF DOCUMENT 14 - 2000: 1. The Otirner deals with one single administrative entity, the Design -Builder, who provides Design Services and Construction of the project under one contract package. 2. The Contract Documents include but not limited to: - Agreement, - Definitions, - General Conditions, - Owner's Statement of Requirements, and - Construction Documents, after they have been accepted by the Owner. 3. After execution of the Contract, Construction Documents are prepared to illustrate the details of the c lesign that meets the Owner's Statement of Requirements. When accepted and signed by bots. the Owner and Design -Builder, these also become part of the Contract Documents. 4. Change Orders are issued to change: - the Work; - the Owner's Statement of Requirements (scope); - the Contract Price, and the Contract Time. 5 . The on] y consultant recognized in the Contract is the Design -Builder's Consultant. The Owner may also appoint representatives or advisors, but they are recognized in the Contract as the Owner's authorized representatives. 6. The roles of the Design -Builder's Consultant are: - i:o design to the Owner's Statement of Requirements and prepare the Construction .documents; i:o be the interpreter of the Contract and Construction Documents in the first instance; - i:o certify to the Design -Builder: to compliance with Construction Documents; Substantial Performance of the Work; 40 progress payments based on the agreed schedule of values. (i) These will be used as support documents to the Design -Builder's applications for payment, or (ii) in the event that the Design -Builder's Consultant is the Payment Certifier, will become the payment certificates that authorize payments to the Design -Builder. 7. The Design -Builder's consultants are bound to fulfil their duties and responsibilities in accordance with the professional standards required by the various professions. The Design- Builder''s consultants are consultants to the Design -Builder to provide the Design Services. This dc,es not preclude them from performing normal professional duties, i.e. certifying payments, issuing certificates for payment, and interpretation of the Contract and Constrb ction Documents. 8. The parties are required to identify the Payment Certifier in the Agreement, whose respons 'bility is to verify a claim and issue certificates for payment. The Payment Certifier may be the Design -Builder's Consultant, Owner, Owner's Advisor, or any knowledgeable third party, as designated by the owner. 9. The Owner's Advisor is the person or entity employed or engaged by the Owner to assist in organiz .ng and administering the design -build selection process and to provide ongoing professional assistance to the Owner during the Project's implementation as required by the Owner. SUMMARY OF IMPORTANT DIFFERENCES BETWEEN THE 1997 AND THE 2000 EDITIONS": 1. Introduce and explain the roles of the Payment Certifier in. Article 5.1.1, Article 6. 1, Definition 14, GC 1.1.3, GC 2.3.3, and Part 5 of the General Conditions. 2. Revise the Definition of Construction Documents to reaffirm that they must meet the general functional intent of the Contract Documents. TABLE OF CONTENTS AGREEMENT BETWEEN OWNER AND DESIGN -BUILDER A-1 The Work A-2 Agreements,, <nd Amendments A-3 Contract Documents A-4 Contract Pric A-5 Payment A-6 Receipt of and Addresses for Notices A-7 Language of rhe Contract A-8 Succession DEFINITIONS OF TH E DESIGN -BUILD STIPULATED PRICE CONTRACT 1. Change Directive 2. Change Order 3. Construction 4. Construction Documents 5. Consultant 6. Contract 7. Contract Documents 8. Contract Pric e 9. Contract Tirr e 10. Design-Builc er H. Design Servi.-es 12. Owner 13. Owner's Stat 1-ment of Requirements 14. Payment Certifier 15. Place of the ' ]Vork 16. Product 17. Project 18. Provide 19. Subcontractc r 20. Substantial F erformance of the Work 21. Supplier 22. Value Addec Taxes 23. Work 24. Working Da; GENERAL CONDITIONS OF THE DESIGN -BUILD STIPULATED PRICE CONTRACT PART 1 GENERAL PROVISIONS GC 1.1 Contract Do ;uments GC 1.2 Owner Supplied Information GC 1.3 Law of the Contract GC 1.4 Rights and F.emedies GC 1.5 Assignment GC 1.6 Confidential ity PART 2 DESIGN SERVICES AND ADMINISTRATION OF THE CONTRACT GC 2.1 Consultant GC 2.2 Owner's Representative GC 2.3 Review and Inspection of the Work GC 2.4 Defective VA ork PART 3 EXECUTION OF THE WORK GC 3.1 Control of the Work GC 3.2 Construction r Documents GC 3.3 Constructioj i by Owner or Other Contractors GC 3.4 Schedule of the Work GC 3.5 Construction Safety GC 3.6 Supervisor GC 3.7 Other Consultants, Subcontractors, and Suppliers GC 3.8 Labour and Products GC 3.9 Documents it the Site GC 3.10 Shop Drawi rigs GC 3.11 Use of the Work GC 3.12 Cutting and Remedial Work GC 3.13 Cleanup GC 3.14 Signage PART 4 ALLOWANCES GC 4.1 Cash Allow ances GC 4.2 Contingenc, ✓ Allowance PART 5 PAYMENT GC 5.1 Financing Information Required of the Owner GC 5.2 Applications for Progress Payment GC 5.3 Progress Payment GC 5.4 Substantial Performance of the Work GC 5.5 Payment of Holdback upon Substantial Performance of the Work GC 5.6 Progressive Release of Holdback GC 5.7 Final Payment GC 5.8 Withholding of Payment GC 5.9 Non -conforming Work PART 6 CHANGES IN THE WORK GC 6.1 Changes GC 6.2 Change Order GC 6.3 Change Directive GC 6.4 Concealed or Unknown Conditions GC 6.5 Delays PART 7 DEFAULT NOTICE GC 7.1 Owner's Right to Perform the Work, Suspend the Work, or Terminate the Contract GC 7.2 Design -Builder's Right to Suspend the Work or Terminate the Contract PART 8 DISPUTE RESOLUTION GC 8.1 Authority of the Consultant GC 8.2 Negotiation, Mediation, and Arbitration GC 8.3 Retention of Rights PART 9 PROTECTION OF PERSONS AND PROPERTY GC 9.1 Protection of Work and Property GC 9.2 Damages and Mutual Responsibility GC 9.3 Toxic and Hazardous Substances and Materials PART 10 GOVERNING REGULATIONS GC 10.1 Taxes and Duties GC 10.2 Laws, Notices, Permits, and Fees GC 10.3 Patent Fees GC 10.4 Workers' Compensation PART 11 INSURANCE - BONDS GC 11.1 Insurance GC 11.2 Bonds PART 12 INDEMNIFICATION - WAIVER - WARRANTY GC 12.1 Indemnification GC 12.2 Waiver of Claims GC 12.3 Warranty Enquiries should be directed to: The Secretary Canadian Construction Documents Committee 400 - 75 Albert Street Ottawa, Ontario KIP 5E7 Tel: (613) 236-9455 Fax: (613) 236-9526 www.ccdc.org CCA, CSC and RAIC Copyright 2000 Must not be copied in whole or in part without written permission from the Canadian Construction Association, Construction Specifications Canada and the Royal Architectural Institute of Canada. Document 14 is the product of a consensus -building process aimed at balancing the interests of all parties on the construction project. It reflects recommended industry practices. Document 14 can have important consequences. The CCA, CSC, and RAIC do not accept any responsibility or liability for loss or damage which may be suffered as a result of the use or interpretation of Document 14. AGREEMENT BETWEEN OWNER AND DESIGN -BUILDER For use when a stipulated price is the basis of payment. This Agreement made as of the 21 day of January in the year 2008 by and between The Corporation of :he Town of Tillsonburg ❑+ hereinafter called th . "Owner" and Gateman-Milloy Inc-. hereinafter called th , "Design -Builder" The Owner and the Design -Builder agree as follows: ARTICLE A-1 THE WORK The Design-Buildej - shall: 1.1 perform & e Work required by the Contract Documents for the Development of Community Trails insert above the title of the Work located at Town of Tillsonburg/Tillsonburg G& C.0 (Concession 5, NTR Middleton, Part Lot 4-6, 1599 P 1 - 500) insert above the Place of the Work for which the Agreement has been signed by the parties, and for which The MBTW Group insert above the name of the Consultant is acting as, and is hereinafter called, the "Consultant", 1.2 do and fulfil everything indicated by the Contract Documents, and 1.3 commence the Work by the 1 day of Februrary in the year 2008 and, subject to adjustment in Contract Time as provided for in the Contract Documents, attain Substantial Performance of the Work: .1 31 day of December in the year 2008 ; or .2 withi 1 weeks after receipt of all approvals from authorities having jurisdiction. (Manually s `Tike out inapplicable paragraph.) CCA -CSC -RAIL Document 14 - 2000 1 This contract is protecOd by copyright. Use of Document 14 not containing a Document 14 copyright seal constitutes an infringement of copyright. Only sign this contract if the doctt ment cover page bears a Document 14 copyright seal to demonstrate that it is intended by the parties to be an accurate and unamended version of Document I � - 2000 except to the extent that any alterations, additions or modifications are set forth in supplementary conditions. .ARTICLE A-2 Al,3REEMENTS AND AMENDMENTS 2.1 The Contract as described in Article A-3 of the Agreement - CONTRACT DOCUMENTS supersedes all prior negotiatioi Is, representations, or agreements, either written or oral, relating in any manner to the Work. 2.2 The Contr qct may be amended only as provided in the Contract Documents. ARTICLE A-3 CONTRACT DOCUMENTS 3.1 The follov ling are the Contract Documents referred to in Article A-1 of the Agreement - THE WORK: - Agret merit Between Owner and Design -Builder - Definitions of the Design -Build Stipulated Price Contract - General Conditions of the Design -Build Stipulated Price Contract - Owner's Statement of Requirements - Consi ruction Documents, after they have been accepted by the Owner Appe.ldix A - Contract Work Schedule & Trail Masterplan * (Insert here attaching additional pages if required, a list identifying all other Contract Documents e.g. Supplementary Conditions; Proposals; Specificatio is, giving a list of contents with section numbers and titles, number of pages, and date; Drawings, giving drawing number, title, date, revision dat ? or mark; Addenda, giving title, number, date) 2 CCA-CSC-RAIC Document 14 — 2000 This contract is protect ?d by copyright. Use of Document 14 not containing a Document 14 copyright seal constitutes an infringement of copyright. Only sign this contract if the docs ment cover page bears a Document 14 copyright seal to demonstrate that it is intended by the parties to be an accurate and unamended version of Document V — 2000 except to the extent that any alterations, additions or modifications are set forth in supplementary conditions. ARTICLE A-4 C1 :)NTRACT PRICE 4.1 The Contract Price, which excludes Value Added Taxes, is: Nine Hun(lred Seventy Nine Thousand Eighty Nine ----------------------------28 /100 dollars $ 979,089.28 4.2 Value Ad6 ed Taxes (of 5 %) payable by the Owner to the Design -Builder are: Forty Eigl t Thousand Nine Hundred Fifty Four--------------------------------- 46 /100 dollars $ 489954.46 4.3 Total amo ant payable by the Owner to the Design -Builder for the Work is: One Million Twenty Eight Thousand Forty Three ------------------------------ 74 /100 dollars $ 19028,043.74 4.4 All amour as are in Canadian funds. 4.5 These amounts shall be subject to adjustments as provided in the Contract Documents. ARTICLE A-5 PAYMENT 5.1 Subject tc the provisions of the Contract Documents, and in accordance with legislation and statutory regulations respecting holdback percentages and, where such legislation or regulations do not exist or apply, subject to a holdback of Ten percent ( 10 %), the Owner shall: .1. make progress payments to the Design -Builder on account of the Contract Price when due in the amount certified by The MBTW Group & Community Trail Committee insert above the name of the Payment Certifier who is acting as, and is hereinafter called, the "Payment Certifier", together with such Value Added Taxes as may be applicable to such payment, and .2 upon Substantial Performance of the Work, pay to the Design -Builder the unpaid balance of the holdback amount when due together with such Value Added Taxes as may be applicable to such payment, and .3 upon the issuance of the final certificate for payment, pay to the Design -Builder the unpaid balance of the Cont -act Price when due together with such Value Added Taxes as may be applicable to such payment. 5.2 In the evf,.nt of loss or damage occurring where payment becomes due under the property and boiler and machinery insurance policies, payments shall be made to the Design -Builder in accordance with the provisions of GC 11.1 - INSURA: ,TCE. 5.3 Interest . l Should either party fail to make payments as they become due under the terms of the Contract or in an award by arbiti ation or court, interest at Five percent ( 5 %) per annum above the prime rate on such unpaid amounts shall also become due and payable until payment. Such interest shall be compounded on a monthly basis. The prime rate shall be the lowest rate of interest quoted by the Royal Bank of Canada for prime business loans. CCA -CSC -RAIL Doct ment 14 — 2000 3 This contract is protect ?d by copyright. Use of Document 14 not containing a Document 14 copyright seal constitutes an infringement of copyright. Only sign this contract if the docs ment cover page bears a Document 14 copyright seal to demonstrate that it is intended by the parties to be an accurate and unamended version of Document 1 , ! — 2000 except to the extent that any alterations, additions or modifications are set forth in supplementary conditions. .2 Interc st shall apply at the rate and in the manner prescribed by paragraph 5.3.1 of this Article on the amount of any claim advanced and for which the Design -Builder is thereafter entitled to payment, either pursuant to Part 8 of the General Conditions - DISPUTE RESOLUTION, or otherwise, from the date the amount would have been due aid payable under the Contract, had it not been in dispute, until the date it is paid. ARTICLE A-6 RECEIPT OF AND ADDRESSES FOR NOTICES 6.1 Notices it writing between the parties or between them and the Consultant shall be considered to have been received by the addressee on the date of delivery if delivered to the individual, or to a member of the firm, or to an officer of the corpoi -ation for whom they are intended by hand or by registered post; or if sent by regular post, to have been delivered within 5 Working Days of the date of mailing when addressed as follows: The Ownc r at 200 Broadway, 2nd Floor street and number and postal box number if applicable Tillsonbur or, Ontario, N4G 5A7 post office or district, province, postal code The Desi -n-Builder at 270 Shoemaker Street street and number and postal box number if applicable Kitchener, Ontario, N2E 3E 1 post office or district, province, postal code The Cons iltant at 255 Wicksteed street and number and postal box number if applicable Toronto, C Intario, M4H 1 G8 post office or district, province, postal code *The Payment Certifier at 255 Wicksteed street and number and postal box number if applicable Toronto, Ontario, M414 1 G8 post office or district, province, postal code * Manually ,strike out this paragraph if inapplicable ARTICLE A-7 LANGUAGE OF THE CONTRACT 7.1 When the Contract Documents are prepared in both the English and French languages, it is agreed that in the event of any appar Ont discrepancy between the English and French versions, the English / FrP(ch * language shall prevail. * Complete this statement by striking out inapplicable term. 7.2 This Agrf ,ement is drawn in English at the request of the parties hereto. La presente convention est redigee en anglais a la dema ade des parties. ARTICLE A-8 SUCCESSION 8.1 The Con, -Tact shall enure to the benefit of and be binding upon the parties hereto, their respective heirs, legal represent; itives, successors, and permitted assigns. 4 CCA-CSC-RAIC Document 14 - 2000 This contract is protect ?d by copyright. Use of Document 14 not containing a Document 14 copyright seal constitutes an infringement of copyright. Only sign this contract if the docs ment cover page bears a Document 14 copyright seal to demonstrate that it is intended by the parties to be an accurate and unamended version of Document 1 - 2000 except to the extent that any alterations, additions or modifications are set forth in supplementary conditions. In witness whereo f the parties hereto have executed this Agreement and by the hands of their duly authorized representatives. SIGNED AND DELIVERED in the presence of: Owner The Co oration of the Town of Tillsonburg name o a signature WITNESS name and title of person signing signature name and title of person, signing Design -Builder Gateman-Milloy In name of Design-Buildej si nature Michael Milloy - P:-esidodi name and title of persqi signing �r4 signatur signature name and title of person signing signature Brett Ritchie - Project Manager name and title of persoi i signing name and title of person signing N. B. Where legal jurisdiction, local practice, or Owner or Design -Builder requirement calls for: (a) proof 9f authority to execute this document, attach such proof of authority in the form of a certified copy of a resolution naming the repres ?ntative(s) authorized to sign the Agreement for and on behalf of the corporation or partnership; or (b) the aff xing of a corporate seal, this Agreement should be properly sealed. CCA-CSC-RAIC Document 14 - 2000 5 This contract is protect, !d by copyright. Use of Document 14 not containing a Document 14 copyright seal constitutes an infringement of copyright. Only sign this contract if the docz, went cover page bears a Document 14 copyright seal to demonstrate that it is intended by the parties to be an accurate and unamended version of Document I S - 2000 except to the extent that any alterations, additions or modifications are set forth in supplementary conditions. DEFINITIONS O F THE DESIGN -BUILD STIPULATED PRICE CONTRACT The following Defi Zitions shall apply to all Contract Documents. 1. Change D irective A Change Directive is a written instruction signed by the Owner directing a change in the Work within the general scope of the Contract Documents. 2. Change C ,rder A Change Order is a written amendment to the Contract signed by the Owner and the Design -Builder stating their agreement upon: - a char ige in the Work; - an am endment to the Owner's Statement of Requirements, if any; - the m nthod of adjustment or the amount of the adjustment in the Contract Price, if any; and - the e)� tent of the adjustment in the Contract Time, if any. 3. Construci .ion Construct 'on means the total construction and related services required by the Contract Documents. 4. Construe, ;ion Documents The Cons (ruction Documents consist of the drawings and specifications that are prepared based on the Contract Documeni s by or on behalf of the Design -Builder and that are accepted and signed by the Owner and the Design - Builder of ter execution of the Agreement, as meeting the general functional intent of the Contract Documents. 5. Consultai it The Cons; sltant is the person or entity identified as such in the Agreement. The term Consultant means the Architect, the Engin 3,er, or entity licensed to practice in the province or territory of the Place of the Work and engaged by the Design -Builder to provide the Consultant's Design Services and to coordinate the provision of the Design Services of all other consultants employed by the Design -Builder. The term Consultant means the Consultant or the Consultant's authorize(, representative as designated by the Design -Builder to the Owner in writing. 6. Contract The Cont -act is the undertaking by the parties to perform their respective duties, responsibilities, and obligations as prescribec in the Contract Documents and represents the entire agreement between the parties. 7. Contract Documents The Coni Tact Documents consist of those documents listed in Article A-3 of the Agreement - CONTRACT DOCUMENTS and amendments thereto agreed upon between the parties. 8. Contract Price The Cont; -act Price is the amount stipulated in Article A-4 of the Agreement - CONTRACT PRICE. 9. Contract Time The Cont Tact Time is the time stipulated in paragraph 1.3 of Article A-1 of the Agreement - THE WORK from commenc ement of the Work to Substantial Performance of the Work. 10. Design -B uilder The Design -Builder is the person or entity identified as such in the Agreement. The term Design -Builder means the Design -B gilder or the Design -Builder's authorized representative as designated by the Design -Builder to the Owner in writing. 11. Design S !rvices Design S ?rvices means the professional services for the design and construction administration performed by the Consultai zt or other consultants under the Contract. CCA-CSC-RAIC Document 14 - 2000 12. Owner The Owner is the person or entity identified as such in the Agreement. The term Owner means the Owner or the Owner's at ithorized agent or representative as designated by the Owner to the Design -Builder in writing. 13. Owner's !�_ -tatement of Requirements The Owner's Statement of Requirements consists of the site information and program requirements provided by the Owner and I as listed in Article A-3 of the Agreement - CONTRACT DOCUMENTS and amendments thereto agreed upon betw Zen the parties. 14. Payment Certifier The Payment Certifier is the person or entity identified as such in the Agreement responsible for the issuance of certificates for payment. The Payment Certifier may be the Consultant, Owner, or any knowledgeable third party, as designated by the Owner. 15. Place of the Work The Place of the Work is the designated site or location of the Construction identified in Article A-1 of the Agreement - THE WORK. 16. Product Product o v Products means material, machinery, equipment, and fixtures forming part of the Work, but does not include machinery and equipment used to prepare, fabricate, convey, or erect the Work, which are referred to as construction machinery and equipment. 17. Project The Proje ;t means the Owner's enterprise of which the Work may be the whole or a part. 18. Provide Provide m eans to supply and install. 19. Subcontr; actor A Subcon, -Tactor is a person or entity, other than the Consultant or other consultants, having a direct contract with the Design -Builder to perform a part or parts of the Work, or to supply Products worked to a special design for the Work. 20. Substantial Performance of the Work Substantic ] Performance of the Work is as defined in the lien legislation applicable to the Place of the Work. If such legislation is not in force or does not contain such definition, or if the Work is governed by the Civil Code of Quebec, Substantic (l Performance of the Work shall have been reached when the Work is ready for use or is being used for the purpose intended and is so certified by the Consultant. 21. Supplier A Supplier is a person or entity having a direct contract with the Design -Builder to supply Products not worked to a special design for the Work. 22. Value Added Taxes !Value Ads led Taxes means such sum as shall be levied upon the Contract Price by the Federal or any Provincial or Territoria Government and is computed as a percentage of the Contract Price and includes the Goods and Services Tax, the Quebec Sales Tax, Harmonized Sales Taxes, and any similar tax, the payment or collection of which, by the legislation imposing such tax, is an obligation of the Design -Builder. 23. Work The Worl means the Design Services and Construction required by the Contract. 24. Working Day Working. 9ay means a day other than a Saturday, Sunday, or a holiday which is observed by the construction industry in the are; i of the Place of the Work. CCA-CSC-RAIC Doct ment 14 — 2000 GENERAL CONIrITIONS OF THE DESIGN -BUILD STIPULATED PRICE CONTRACT PART 1 GENEIL �L PROVISIONS GC 1.1 CONTRACT DOCUMENTS 1.1.1 The intent of the Contract Documents is to include the Design Services, Construction, and other services necessary for the perfon riance of the Work in accordance with these documents. It is not intended, however, that the Design -Builder shall supp' y products or perform work not consistent with, not covered by, or not properly inferable from the Contract Document Y. 1.1.2 Nothing c, )ntained in the Contract Documents shall create any contractual relationship between the Owner and the Consultant, an other consultant, a Subcontractor, a Supplier, or their agent, employee, or any other person performing any of the Work. 1.1.3 If the Payment Certifier is not the Consultant or the owner, the owner shall, if requested in writing by the Design - Builder, d sclose the contractual relationship between the owner and the Payment Certifier by provision of a copy of the contrast with the Payment Certifier to the Design -Builder. 1.1.4 The Contr get Documents are complementary, and what is required by any one shall be as binding as if required by all. 1.1.5 Words and 1 abbreviations which have well known technical or trade meanings are used in the Contract Documents in accordanc .- with such recognized meanings. 1.1.6 Reference 5, in the Contract Documents to the singular shall be considered to include the plural as the context requires. 1.1.7 The speci- -ications are that portion of the Contract Documents, wherever located and whenever issued, consisting of the writte 1 requirements and standards for Products, systems, workmanship, and the services necessary for the performance of the Construction. 1.1.8 The draw ngs are the graphic and pictorial portions of the Contract Documents, wherever located and whenever issued, showing the design, location, and dimensions of the Construction, generally including plans, elevations, sections, c etails, schedules, and diagrams. 1.1.9 Neither th - organization of the specifications into divisions, sections, and parts, nor the arrangement of drawings shall control th(, Design -Builder in dividing the work among Subcontractors and Suppliers or in establishing the extent of the work to be performed by a trade. 1.1.10 If there is a conflict within the Contract Documents: .1 the of der of priority of documents, from highest to lowest, shall be t ie Agreement between the Owner and the Design -Builder, t ie Definitions, , upplementary Conditions, t -ie General Conditions, - Vie owner's Statement of Requirements, Vie Construction Documents: Division 1 of the specifications, Divisions 2 through 1.6 of the specifications, material and finishing schedules, drawings. .2 drawings of larger scale shall govern over those of smaller scale of the same date. .3 dime -isions shown on drawings shall govern over dimensions scaled from drawings. .4 later dated documents shall govern over earlier documents of the same type. 1.1.11 Copyrigh : for the design and drawings prepared by or on behalf of the Design -Builder belongs to the Consultant or other con ;ultants who prepared them. 1.1.12 Plans, ski itches, drawings, graphic representations, and specifications, including computer generated designs, when prepared by the Consultant, or other consultants are instruments of their service and shall remain their property whether t pie Construction for which they are made is executed or not. CCA-CSC-RAIC Document 14 — 2000 1.1.13 Submissio:ls or distribution of the Consultant or other consultants' plans, sketches, drawings, graphic representations, and specif cations to meet official regulatory requirements or for other purposes in connection with the Work is not to be construt -.d as publication in derogation of their reserved rights. 1.1.14 The Owner may retain copies, including reproducible copies, of plans, sketches, drawings, graphic representations, and specifications for information and reference in connection with the Owner's design and construction and the Owner's u ;e and occupancy of the Work. As a condition precedent to the use of such documents, the Owner shall have paid - n full for any Design Services rendered. The Design -Builder will, prior to any payment being issued under this Cono act. deliver to the Owner a consent and acknowledgement signed by the Consultant confirming the Consultan "s agreement that the Owner may use any material produced by the Consultant and in which the Consultant retains an) copyright in the manner set forth in paragraphs 1.1.13 to 1.1.16. 1.1.15 Except for reference purposes, the plans, sketches, drawings, graphic representations, and specifications shall not be used for additions or alterations to the Work or on any other project. 1.1.16 Models and architectural renderings furnished by the Design -Builder at the Owner's expense are the property of the Owner. GC 1.2 OWNER 'SUPPLIED INFORMATION 1.2.1 Unless thf � Contract Documents specifically state otherwise, the Design -Builder, Consultant and other consultants may rely (,n the accuracy and completeness of all information provided by the Owner without regard for the source of such infor. nation. 1.2.2 Notwithstanding any other provision of the Contract, the Design -Builder is not responsible for any design errors or omissions in any designs or specifications provided by or on behalf of the Owner unless the Design -Builder has been specifically requested to review and has accepted in writing those designs and specifications under the Contract. 1.2.3 The Owner shall furnish the information and services required under the Contract promptly to avoid delay in the performance of the Contract. 1.2.4 The Owner's Statement of Requirements may include: .1 site i-iformation e.g. site description, topographical and boundary surveys, environmental, geotechnical and design rated substance investigation reports, utility information, and covenants and restrictions on the property; and .2 the Owner's program requirements e.g. design objectives and parameters, performance requirements, constraints and c-iteria, spatial and functional requirements and relationships, flexibility and potential for expansion, special equipment and systems, and site requirements and budget. 1.2.5 The Desi ,n -Builder shall review the Owner's Statement of Requirements and shall report promptly to the Owner any significan , error, inconsistency, or omission the Design -Builder may discover. 1.2.6 The review by the Design -Builder under paragraph 1.2.5 shall be to the best of the Design -Builder's knowledge, information, and belief and in making such review the Design -Builder does not assume any responsibility to the Owner for the accuracy of the review with respect to the Owner's Statement of Requirements prepared by or on behalf of the Owner. 1.2.7 The Desi ,n -Builder shall not be liable for damage or costs resulting from such errors, inconsistencies, or omissions in the Owner's Statement of Requirements prepared by or on behalf of the Owner which the Design -Builder did not discover. 1.2.8 If the De sign -Builder does discover any significant error, inconsistency, or omission in the O'wner's Statement of Requirements prepared by or on behalf of the Owner, the Design -Builder shall not proceed with the work affected until the Design -Builder and the Owner have discussed how the information should be corrected or supplied. GC 1.3 LAW OF THE CONTRACT 1.3.1 The law c f the Place of the Work shall govern the interpretation of the Contract. GC 1.4 RIGHTS AND REMEDIES 1.4.1 Except a5, expressly provided in the Contract Documents, the duties and obligations imposed by the Contract Documents and the rights and remedies available thereunder shall be in addition to and not a limitation of any duties, obligation is, rights, and remedies otherwise imposed or available by law. CCA-CSC-RAIC Doct iment 14 — 2000 1.4.2 Except as Axpressly provided in the Contract Documents, no action or failure to act by the Owner, Design -Builder, or the Consu,'tant shall constitute a waiver of any right or duty afforded any of them under the Contract, nor shall any such actio 1 or failure to act constitute an approval of or acquiescence in any breach thereunder, except as may be specificall,, agreed to in writing. GC 1.5 ASSIGNnTENT 1.5.1 Neither pC- rty to the Contract shall assign all or any part of the Contract without the written consent of the other, which con Sent shall not be unreasonably withheld. GC 1.6 CONFIDENTIALITY 1.6.1 The Owncr and the Design -Builder shall keep confidential all matters respecting technical, commercial, and legal issues rela ting to or arising out of the Work or the performance of the Contract and shall not, without the prior written consent of the other party, disclose any such matters, except in strict confidence, to its professional advisors. PART 2 DESIGN SERVICES AND ADMINISTRATION OF THE CONTRACT GC 2.1 CONSULTANT 2.1.1 The Desi n -Builder shall engage the Consultant under a contract pursuant to which the Consultant's services, duties and responsibilities will include: .1 the re view of the Owner's Statement of Requirements; .2 the review with the Owner of reasonable alternative approaches to the design; .3 the preparation of a design that meets the criteria set forth in the Contract Documents; .4 the cc ordination required to integrate all parts of the Design Services, .5 the pi eparation of schematic design documents to illustrate the scale and character of the Work and how the parts of the Work functionally relate to each other; .6 the pi •eparation of design development documents, based on the schematic design documents accepted by the Ownc r, consisting of drawings and other documents appropriate to the size of the Work to describe the size and chara -ter of the entire Work including architectural, mechanical and electrical systems, materials, and such other elemc nts as may be appropriate; .7 the pl eparation of Construction Documents setting forth in detail the requirements for Construction based on the desig- i development documents accepted by the Owner; .8 the p -ovision of assistance to the Owner and Design -Builder to obtain approvals, permits, and licenses for the Cons. `ruction, .9 the conducting of general review of the progress of the Construction, to the extent necessary, in order to deters nine to the Consultant's satisfaction that the Construction is performed in general conformity with the requirements of. (1) The Contract Documents, and (2) The applicable statutes, regulations, codes, and bylaws of all authorities having jurisdiction over the Work; .10 the assurances required by regulatory authorities respecting substantial conformance of the design with the applii -,able building regulations, other than construction safety issues; .11 the pl,•eparation of Change Orders and Change Directives as set out in GC 6.2 - CHANGE ORDER and GC 6.3 - CHANGE DIRECTIVE; .12 the di-termining of amounts owing to the Design -Builder based on the Consultant's observations and evaluation of the L ,esign-Builder's applications for payment; .13 the i ;suance of certificates for payment in the value proportionate to the amount of the Contract, for Work perfc rmed and Products delivered to the Place of the Work; .14 the interpretation, in the first instance, of the requirements of the Construction Documents and the making of findings as to the performance thereunder by both the Owner and the Design -Builder without showing partiality to either the Owner or the Design -Builder, and in no event incurring liability for the result of such interpretations or fir .dings rendered in good faith in such capacity; .15 the it iterpretation and finding, in the first instance, of claims, disputes, and other matters in question relating to the perfc rmance of the Work or the interpretation of the Contract Documents, except for GC 5.1 - FINANCING INFORMATION REQUIRED OF THE OWNER. .16 the rejecting of work which does not conform to the requirements of the Contract Documents; 10 CCA-CSC-RAIC Document 14 — 2000 .17 the requiring of special testing and inspection of the Construction at the sole discretion of the Consultant, whether or not such Construction has been fabricated, installed, or completed; .18 the dE.termining of the date of Substantial Performance of the Work and the issuing of a certificate attesting to same: .19 the vE rification of the Design -Builder's application for final payment and the issuing of a certificate for payment; .20 the reviewing of any defects or deficiencies in the Work during the period described in GC 12.3 - WARRANTY and t1 ie issuance of appropriate instructions for the correction of same; and .21 such other work that may be required from time to time that is agreed to by the Owner and the Design -Builder in writir g and is acceptable to the Consultant. 2.1.2 In perforn ling the above duties, the Consultant will provide the necessary services as expeditiously as is required for the order],, progress of the Work. 2.1.3 All certift-ates issued by the Consultant shall be to the best of the Consultant's knowledge, information, and belief. By issuing; any certificate, the Consultant does not guarantee the Work is correct or complete. 2.1.4 The Consaltant shall perform the Design Services and fulfil the Consultant's duties and responsibilities to the standard of diligen -.e, skill, and care that consultants would customarily provide in similar circumstances and in the same relative go: ographic location, subject to the Consultant's professional and legal obligations. 2.1.5 The Owncr waives any right of action in negligence or otherwise against the Consultant or any other consultant employed by the Design -Builder in respect of performance of the Design Services except to the extent the Owner may be entitles to make a claim against the Design -Builder under the Contract. 2.1.6 If the Co gsultant's engagement is terminated, the Design -Builder shall engage a new Consultant to provide the Consultay is services. The Design -Builder shall notify the (honer in writing before appointing or reappointing a Consultar, t to provide the Design Services. The Design -Builder shall not appoint any Consultant to whom the Owner may reasonably object. GC 2.2 OWNER'S REPRESENTATIVE 2.2.1 The Owner shall designate a representative authorized to act on the Owner's behalf and shall specify in written notice to the Des ign-Builder any limits on the representative's authority. 2.2.2 Subject to any notified limitations in authority, the Design -Builder may rely upon any written instructions or directions provided by the Owner's representative. 2.2.3 The Owner's representative shall take all reasonable steps to be accessible to the Design -Builder during performance of the Contract and shall render any necessary decisions or instructions promptly to avoid delay in the performance of the Contract. . 2.2.4 The Owner and Owner's representatives shall not communicate with any Subcontractors performing the Work except through tI e Design -Builder or a person designated by the Design -Builder. GC 2.3 REVIEVA AND INSPECTION OF THE WORK 2.3.1 The Design -Builder shall . l perm I the Owner to review all material aspects of the design of the Work as the design proceeds, and .2 provi Je a copy of all drawings, specifications, and diagrams to the Owner when required for review and acceptance. 2.3.2 From time.-, to time, the Design -Builder may request and, on request, the Owner shall examine certain aspects of the design as set out on design development documents or Construction Documents to confirm that the design aspects are in general compliance with: .1 the q jalitative, functional layout, operational, and other Owner requirements for the Work; and .2 the standards of finish, comfort, or aesthetics as required by the Contract Documents. 2.3.3 The Own,,r, the Consultant and the Payment Certifier shall have access to the Construction at all times. The Design - Builder s:lall provide sufficient, safe, and proper facilities at all times for their review of the Construction and the inspection of the Construction by authorized agencies. If parts of the Construction are in preparation at locations other than the Place of the Work, the Owner, the Consultant and the Payment Certifier shall be given access to such work whc never it is in progress. CCA-CSC-RAIC Doct.ment 14 — 2000 11 2.3.4 If work is designated for tests, inspections, or approvals in the Contract Documents, or by the instructions of the Owner or 1 he Consultant, or the laws or ordinances of the Place of the Work, the Design -Builder shall give the Owner reasonable notice of when the work will be ready for review and inspection. The Design -Builder shall arrange for and shall give :he Owner reasonable notice of the date and time of inspections by other authorities. 2.3.5 The Design -Builder shall furnish promptly to the Consultant and to the Owner, on request, a copy of certificates and inspection reports relating to the Work. 2.3.6 If the Des, gn-Builder covers, or permits to be covered, work that has been designated for special tests, inspections, or approvals before such special tests, inspections, or approvals are made, given or, completed, the Design -Builder shall, if so direc :ed, uncover such work, have the inspections or tests satisfactorily completed, and make good the covering work at th . Design -Builder's expense. 2.3.7 The Ownc r may order any portion or portions of the Construction to be examined to confirm that such work is in accordancl., with the requirements of the Contract Documents. If the work is not in accordance with the requirements of the Cor, tract Documents, the Design -Builder shall correct the work and pay the cost of examination and correction. If the work is in accordance with the requirements of the Contract Documents, the Owner shall pay all costs incurred by the Deicign-Builder as a result of such examination and restoration. 2.3.8 The Conn chant shall provide any required assurances to regulatory authorities respecting substantial conformance of the Conso uction with the design approved by that authority for issuance of the building permit. GC 2.4 DEFECTIVE WORK 2.4.1 The Design -Builder shall promptly remove from the Place of the Work and replace or re -execute defective work that has been rejected by the Consultant as failing to conform to the Contract Documents whether or not the defective work has been incorporated in the Work and whether or not the defect is the result of poor workmanship, design, use of defective products, or damage through carelessness or other act or omission of the Design -Builder. 2.4.2 The Desi€ ,n -Builder shall make good promptly other contractors' work destroyed or damaged by such removals or replacements at the Design -Builder's expense. 2.4.3 If, in the c pinion of the Owner, it is not expedient to correct defective work or work not performed as provided in the Contract Documents, the Owner may deduct from the amount otherwise due to the Design -Builder the difference in value between the work as performed and that called for by the Contract Documents. If the Design -Builder does not agree on ,he difference in value, the Design -Builder shall refer the dispute to Part 8 of the General Conditions - DISPUTE RESOLUTION. PART 3 EXECurION OF THE WORK GC 3.1 CONTROL OF THE WORK 3.1.1 The Desig ,n -Builder shall have total control of the Work and shall effectively direct and supervise the Work so as to ensure conformity with the Contract Documents. 3.1.2 The Design -Builder shall be solely responsible for construction means, methods, techniques, sequences, and procedure S with respect to the Construction and for co-ordinating the various parts of the Construction under the Contract. 3.1.3 The Desig -n-Builder shall keep the Owner informed of the progress of the Work. 3.1.4 The Desig ,n -Builder is solely responsible for the quality of the Work and shall undertake any quality control activities specified n the Contract Documents or, if none are specified, as may be reasonably required to ensure such quality. GC 3.2 CONSTRUCTION DOCUMENTS 3.2.1 During the progress of the Work, the Design -Builder shall furnish to the Owner the Construction Documents that describe details of the design required by the Contract Documents. At the time of submission the Design -Builder shall notify the Owner in writing of any significant deviations in the Construction Documents from the requirement of the Contract Documents. 12 CCA-CSC-RAIC Document 14 — 2000 3.2.2 The Desi n -Builder shall submit the Construction Documents to the Owner to review in orderly sequence and sufficiently 1 in advance so as to cause no delay in the Work. Upon request of the Owner or the Design -Builder, they jointly shall prepare a schedule of the dates for submission and return of Construction Documents. 3.2.3 The Owne � shall review the Construction Documents in accordance with the schedule agreed upon, or in the absence of an agree Jd schedule with reasonable promptness so as to cause no delay. The Owner's review is for conformity to the intent of the Contract Documents. The Owner's review shall not relieve the Design -Builder of responsibility for errors or omissions in the Construction Documents or for meeting all requirements of the Contract Documents unless the Owner expressly accepts a deviation from the Contract Documents. 3.2.4 No later th an 7 days after completing the review, the Owner shall notify the Design -Builder in writing that the Owner has accept. -.d and has signed the Construction Documents or shall notify the Design -Builder, giving reasons in writing, why the Owner rejects the Construction Documents. Upon request by the Owner, the Design -Builder shall revise and resubmit Construction Documents which the Owner has rejected. The Design -Builder shall notify the Owner in writing of any revisions to any resubmission other than those requested by the Owner. 3.2.5 When the Construction Documents are accepted and signed by the Owner and the Design Builder such Construction Documem shall become part of the Contract Documents. 3.2.6 When a ct ange is required to the Construction Documents that have been accepted and signed by the Owner, it shall be made irl, accordance with GC 6.1 - CHANGES, GC 6.2 - CHANGE ORDER, or GC 6.3 - CHANGE DIRECTIVE. GC 3.3 CONSTRUCTION BY OWNER OR OTHER CONTRACTORS 3.3.1 The Owncr reserves the right to award separate contracts in connection with other parts of the Project to other contractor:- and to perform work with own forces. 3.3.2 When separate contracts are awarded for other parts of the Project, or when work is performed by the Owner's own forces, the Owner shall: .l provide for the co-ordination of the activities and work of other contractors and Owner's own forces with the Work of the Contract; .2 assurr e overall responsibility for compliance with the applicable health and construction safety legislation at the Place o, f the Work; .3 enter into separate contracts with other contractors under conditions of contract which are compatible with the condi-:ions of the Contract; .4 ensure - that insurance coverage is provided to the same requirements as are called for in GC 11.1 — INSURANCE and co-ordinate such insurance with the insurance coverage of the Design -Builder as it affects the Work; and .5 take o ll reasonable precautions to avoid labour disputes or other disputes on the Project arising from the work of other contractors or the Owner's own forces. 3.3.3 When separate contracts are awarded for other parts of the Project, or when work is performed by the Owner's own forces, the Design -Builder shall: . l afford. the Owner and other contractors reasonable opportunity to introduce and store their products and use their construction machinery and equipment to execute their work; .2 co-ordinate and schedule the Work with the work of other contractors and Owner's own forces and connect as specified or shown in the Contract Documents; .3 participate with other contractors and the Owner in reviewing their schedules when directed by the Owner; and .4 where part of the Work is affected by or depends upon for its proper execution the work of other contractors or Ownc is own forces, promptly report to the Owner in writing and prior to proceeding with that part of the Work, any apparent deficiencies in such work. Failure by the Design -Builder to so report shall invalidate any claims against the Owner by reason of the deficiencies in the work of other contractors or Owner's own forces except those deficiencies not then reasonably discoverable. 3.3.4 Where a change in the Work is required as a result of the co-ordination and connection of the work of other contractor s or Owner's own forces with the Work, the changes shall be authorized and valued as provided in GC 6.1 - CHANGES, GC 6.2 - CHANGE ORDER, and GC 6.3 - CHANGE DIRECTIVE. 3.3.5 Claims, d sputes, and other matters in question between the Design -Builder and other contractors shall be dealt with as provided in Part 8 of the General Conditions - DISPUTE RESOLUTION provided the other contractors have reciprocal obligations. The Design -Builder shall be deemed to have consented to arbitration of any dispute with any other contractor whose contract with the Owner contains a similar requirement to arbitrate such dispute. CCA -CSC -RAIL Document 14 — 2000 13 GC 3.4 SCHEDULE OF THE WORK 3.4.1 The Design -Builder shall: .1 prepare and submit to the Owner prior to the first application for payment, a schedule of the Work that indicates the timing of the major activities of the Work and provides sufficient detail of the critical events and their inter- relationship to demonstrate the Work will be performed in conformity with the Contract Time; .2 monitor the progress of the Design Services and Construction relative to the schedule of the Work and update the schedule on a monthly basis or as stipulated by the Contract Documents; and .3 advise. the Owner in writing of any revisions required to the schedule as the result of extensions of the Contract Time as provided in Part 6 of the General Conditions - CHANGES IN THE WORK. GC 3.5 CONSTRUCTION SAFETY 3.5.1 Subject tc paragraph 3.3.2.2 of GC 3.3 - CONSTRUCTION BY OWNER OR OTHER CONTRACTORS, the Design-Bvilder shall be solely responsible for construction safety at the Place of the Work and for compliance with the rules, regulations, and practices required by the applicable construction health and safety legislation and shall be responsibl; for initiating, maintaining, and supervising all safety precautions and programs in connection with the performance of the Construction. GC 3.6 SUPERVISOR 3.6.1 The Design -Builder shall employ a competent supervisor and necessary assistants who shall be in attendance at the Place of ti'le Work while the Construction is being performed. The supervisor shall not be changed except for valid reason. 3.6.2 The supervisor shall represent the Design -Builder at the Place of the Work and notices and instructions given to the supervisor by the Owner shall be held to have been received by the Design -Builder. GC 3.7 OTHER (""ONSULTANTS, SUBCONTRACTORS, AND SUPPLIERS 3.7.1 The Design -Builder shall preserve and protect the rights of the parties under the Contract with respect to work to be performed under subcontract, and shall: .1 enter into contracts or written agreements with the Consultant, and other consultants to require them to perform their design and other services as provided in the Contract Documents, .2 enter into contracts or written agreements with Subcontractors and Suppliers to require them to perform their work and related services as required by the Contract Documents; .3 incorporate the terms and conditions of the Contract Documents into all contracts or written agreements with the Consultant, other consultants, Subcontractors, and Suppliers insofar as they are applicable; and .4 be as fully responsible to the Owner for acts and omissions of the Consultant, other consultants, Subcontractors, Suppliers, and of persons directly or indirectly employed by them as for acts and omissions of persons directly employed by the Design -Builder. 3.7.2 The Design -Builder shall indicate in writing, at the request of the Owner, other consultants, Subcontractors, or Suppliers whose proposals or bids have been received by the Design -Builder which the Design -Builder would be prepared to accept for the performance of a portion of the Work. Should the Owner not object before signing the Contract, the Design -Builder shall employ other consultants, Subcontractors, or Suppliers so identified by the Design - Builder in writing for the performance of that portion of the Work to which their proposal or bid applies. 3.7.3 The Owner may, for reasonable cause, at any time before the Design -Builder has signed the subcontract, object to the use of a proposed other consultant, Subcontractor, or Supplier and require the Design -Builder to employ another proposed other consultant or subcontract bidder. 3.7.4 If the Owner requires the Design -Builder to change a proposed other consultant, Subcontractor, or Supplier, the Contract .price and Contract Time shall be adjusted by the differences occasioned by such required change. 3.7.5 The Design -Builder shall not be required to employ as an other consultant, Subcontractor, or Supplier, a person or firm to whom the Design -Builder may reasonably object. 3.7.6 The Owner may provide to other consultants, Subcontractors, or Suppliers information as to the percentage of their work which has been certified for payment. 14 CCA-CSC-RAIC Document 14 — 2000 GC 3.8 LABOUR AND PRODUCTS 3.8.1 The Design -Builder shall provide and pay for labour, Products, tools, construction machinery and equipment, water, heat, light, power, transportation, and other facilities and services, including Design Services, necessary for the performance of the Work in accordance with the Contract. 3.8.2 Unless otherwise specified, all Products provided shall be new. Products which are not specified shall be of a quality consistent with those similar products specified. 3.8.3 The Design -Builder shall maintain good order and discipline among the Design -Builder's employees engaged on the Work and shall not employ on the Work anyone not skilled in the tasks assigned. GC 3.9 DOCUMENTS AT THE SITE 3.9.1 The Design -Builder shall keep one copy of current Contract Documents, submittals, reports, and records of meetings at the Place of the Work, in good order and available to the Owner. GC 3.10 SHOP DRAWINGS 3.10.1 Shop dramrings are drawings, diagrams, illustrations, schedules, performance charts, brochures, product, and other data which illustrate details of a portion of the Work. 3.10.2 The Design -Builder shall provide shop drawings as described in the Contract Documents or as the Owner may reasonable request. 3.10.3 The Desi€rn-Builder, the Consultant and where appropriate, other consultants, shall review all shop drawings. The Design -Builder represents by this review that: the Design -Builder has determined and verified all field measurements and field construction conditions, or will do so; Product requirements; catalogue numbers; and similar data and that the Desig,i-Builder has checked and coordinated each shop drawing with the requirements of the Work and of the Contract Documents. 3.10.4 Shop drawings which require approval of any authority having jurisdiction shall be submitted to such authority by the Design -Builder. 3.10.5 If the Owner requests to review shop drawings, the Design -Builder shall submit them in orderly sequence and sufficiently in advance so as to cause no delay in the Work or in the work of other contractors. The Owner and the Design -Builder shall jointly prepare a schedule of the dates for submission and return of shop drawings. 3.10.6 The Owner's review under paragraph 3.10.5 is for conformity to the intent of the Contract Documents and for general arrangement only. The Owner's review shall not relieve the Design -Builder of the responsibility for errors or omissions in the shop drawings or for meeting all requirements of the Contract Documents unless the Owner expressly accepts a deviation from the Contract Documents. GC 3.11 USE OF THE WORK 3.11.1 The Desil;n-Builder shall confine construction machinery and equipment, storage of Products, and operations of employees to limits indicated by laws, ordinances, permits, or the Contract Documents and shall not unreasonably encumber the Construction. 3.11.2 The Design -Builder shall not load or permit to be loaded any part of the Construction with a weight or force that will endanger -the safety of the Project. GC 3.12 CUTTING AND REMEDIAL WORK 3.12.1 The Design -Builder shall do the cutting and remedial work required to make the several parts of the Construction come together properly. 3.12.2 The Design -Builder shall co-ordinate the Work to ensure that this requirement is kept to a minimum. 3.12.3 Cutting and remedial work shall be performed by specialists familiar with the Products affected and shall be performed in a manner to neither damage nor endanger the Construction. CCA-CSC-RAIC Document 14 — 2000 15 GC 3.13 CLEANUP 3.13.1 The Design -Builder shall maintain the Place of the Work in a tidy condition and free from the accumulation of waste products and debris, other than that caused by the Owner, other contractors, or their employees. 3.13.2 The Design -Builder shall remove waste products and debris, other than that resulting from the work of the Owner, other contractors, or their employees, and shall leave the Place of the Work clean and suitable for occupancy by the Owner before attainment of Substantial Performance of the Work. The Design -Builder shall remove products, tools, construction machinery, and equipment not required for the performance of the remaining work. 3.13.3 Prior to application for the final certificate for payment, the Design -Builder shall remove products, tools, construction machinery and equipment, and waste products and debris, other than that resulting from the work of the Owner, other contractors, or their employees. GC 3.14 SIGNAGE 3.14.1 Unless reasonably objected by the Owner, the Design -Builder and the Consultant shall be entitled to sign the building by inscription or otherwise on a suitable and reasonably visible part of the permanent fabric of the building. 3.14.2 The Design -Builder may erect a sign identifying the Design -Builder, the Consultant, other consultants, and Subcontractors at the Place of the Work during the construction. PART 4 ALLOWANCES GC 4.1 CASH ALLOWANCES 4. l .1 The Conti -act Price includes cash allowances stated in the Contract Documents, which allowances shall be expended as the Owaer directs. 4.1.2 Cash allowances cover the net cost to the Design -Builder of services, Products, construction machinery and equipment:, freight, unloading, handling, storage, installation, and other authorized expenses incurred in performing the Work :Stipulated under the cash allowances but do not include any Value Added Taxes payable by the Owner to the Design -Builder. 4.1.3 The Contract Price, and not the cash allowances, includes the Design -Builder's overhead and profit in connection with such cash allowances. 4.1.4 Where costs under a cash allowance exceed the amount of the allowance, the Design -Builder shall be compensated for any excess, incurred and substantiated plus an amount for overhead and profit as provided in GC 6.1 - CHANGES. 4.1.5 The Contract Price shall be adjusted by Change Order to provide for any difference between the actual cost and each cash allowance. 4.1.6 The value of the Work performed under a cash allowance is eligible to be included in progress payments. 4.1.7 The Design -Builder and the Owner shall jointly prepare a schedule that shows when the Owner must authorize ordering of items called for under cash allowances to avoid delaying the progress of the Work. GC 4.2 CONTINGENCY ALLOWANCE 4.2.1 The Conti -act Price includes the contingency allowance, if any, stated in the Contract Documents. 4.2.2 Expenditures under the contingency allowance shall be authorized and valued as provided in GC 6.1 - CHANGES, GC 6.2 - CHANGE ORDER, and GC 6.3 - CHANGE DIRECTIVE. 4.2.3 The Contract Price shall be adjusted by Change Order to provide for any difference between the expenditures authorized under paragraph 4.2.2 and the contingency allowance. 16 CCA-CSC-RAIC Document 14 — 2000 PART 5 PAYMENT GC 5.1 FINANCING INFORMATION REQUIRED OF THE OWNER 5.1.1 The owner shall, at the request of the Design -Builder, prior to execution of the Agreement, and promptly from time to time as requested thereafter, furnish to the Design -Builder reasonable evidence that financial arrangements have been made to fulfil the Owner's obligations under the Contract. 5.1.2 The Owner shall notify the Design -Builder in writing of any material change in the owner's financial arrangements during the performance of the Contract. GC 5.2 APPLICATIONS FOR PROGRESS PAYMENT 5.2.1 Applications for payment on account as provided in Article A-5 of the Agreement - PAYMENT may be made monthly as the Work progresses. 5.2.2 The Design -Builder shall submit to the Owner, at least 14 days before the first application for payment, a schedule of values for the parts of the Work, aggregating the total amount of the Contract Price, so as to facilitate evaluation of applications for payment. 5.2.3 The schedule of values shall be made out in such form and supported by such evidence as accepted by the owner and shall be used as the basis for applications for payment, unless it is found to be in error. 5.2.4 Applications for payment shall be dated the last day of the agreed monthly payment period. They shall be issued to the Owner and unless the Payment Certifier is identified to be the Consultant, to the Payment Certifier. The amount claimed shall be for the value, proportionate to the amount of the Contract, of Work performed and Products delivered to the Place of the Work at that date. 5.2.5 The Design -Builder shall include a statement based on the schedule of values with each application for payment and a certificate for payment issued by the Consultant to the Design -Builder in the amount applied for by the Design - Builder. 5.2.6 Claims for Products delivered to the Place of the Work but not yet incorporated into the Work shall be supported by such evidence as the Owner may reasonably require to establish the value and delivery of the Products. GC 5.3 PROGRESS PAYMENT 5.3.1 If the Payment Certifier is not the Consultant or the Owner, the Payment Certifier will issue to the Owner, and if the Payment Certifier is the Owner, the owner shall issue, no later than 10 days after the receipt of an application for payment from the Design -Builder submitted in accordance with GC 5.2 — APPLICATION FOR PROGRESS PAYMENT, a certificate for payment in the amount applied for or in such other amount as the Payment Certifier determines to be properly due. If the Payment Certifier amends the application, the Payment Certifier will promptly notify the Design -Builder in writing giving reasons for the amendment. 5.3.2 The Owner shall make payment to the Design -Builder on account as provided in Article A-5 of the Agreement — PAYMENT no later than 15 days after the receipt of a certificate for payment issued by the Payment Certifier or after the Owner has issued a certificate as contemplated by paragraph 5.3.1. GC 5.4 SUBSTANTIAL PERFORMANCE OF THE WORK 5.4.1 When the Design -Builder considers that the Work is substantially performed, or if permitted by the lien legislation applicable to the Place o, f ' the Work a designated portion thereof which the Owner agrees to accept separately is substantially performed, the Design -Builder shall prepare and submit to the owner a comprehensive list of items to be completed or corrected and apply for a review by the Owner. Failure to include an item on the list does not alter the responsibility of the Design -Builder to complete the Contract. 5.4.2 The Design -Builder's list and application for Substantial Performance of the Work shall include a statement from the Consultant representing to the Design -Builder the validity of the list and the date of Substantial Performance of the Work or designated portion of the Work. Where required by the applicable lien legislation, the Consultant shall issue a certificate of Substantial Performance of the Work. CCA-CSC-RAIC Docullment 14 — 2000 17 5.4.3 If the Consultant is not the Payment Certifier and the applicable lien legislation requires the Payment Certifier to determine whether the Contract has been substantially performed, the Owner shall require the Payment Certifier within 7 days after receipt of the Design -Builder's application for Substantial Performance of the Work issue a certificate of the Substantial Performance of the Work which shall state the date of Substantial Performance of the Work or advise the Design -Builder in writing of the reasons for which such a certificate is not issued. 5.4.4 Immediately following the issuance of a certificate of Substantial Performance of the Work, the Design -Builder, in consultation with the Owner, will establish a reasonable date for finishing the Work. GC 5.5 PAYMENT OF HOLDBACK UPON SUBSTANTIAL PERFORMANCE OF THE WORK 5.5.1 After the issuance of the certificate of Substantial Performance of the Work as in accordance with GC 5.4 — SUBSTANTIAL PERFORMANCE OF THE WORK, the Design -Builder shall: . l submit an application for payment of the holdback amount, .2 submit a sworn statement that all accounts for the Design Services, labour, subcontracts, Products, construction machinery and equipment, and other indebtedness which may have been incurred by the Design -Builder in the Substantial Performance of the Work and for which the Owner might in any way be held responsible have been paid in full, except for amounts properly retained as a holdback or those amounts not yet paid by the Owner to the Design -Builder for Work done which amounts in the Design -Builder's hands would be payable by the Design - Builder to those with whom it is bound by contract for the performance of the Work or any amounts identified by the Design -Builder, the payment of which is in dispute. 5.5.2 After the receipt of an application for payment from the Design -Builder and the sworn statement as provided in paragraph 5.5.1, the Payment Certifier will issue a certificate for payment of the holdback amount. 5.5.3 Where the holdback amount has not been placed in a separate holdback account as may be required by the lien legislation applicable to the Place of the Work, the Owner shall, 10 days prior to the expiry of the holdback period stipulated in the lien legislation applicable to the Place of the Work, place the holdback amount in a bank account in the joint names of the Owner and the Design -Builder. In the Common Law provinces GC 5.5.4 shall read as follows: 5.5.4 The holdback amount authorized by the certificate for payment of the holdback amount is due and payable on the day following the expiration of the holdback period stipulated in the lien legislation applicable to the Place of the Work. Where lien legislation does not exist or apply, the holdback amount shall be due and payable in accordance with other legislation, industry practice, or provisions which may be agreed to between the parties. The Owner may retain out of the holdback amount any sums required by law to satisfy any liens against the Work or, if permitted by the lien legislation applicable to the Place of the Work, other third party monetary claims against the Design -Builder which are enforceable against the Owner. In the Province of Quebec GC 5.5.4 shall read as follows: 5.5.4 The holdback amount authorized by the certificate for payment of the holdback amount is due and payable no later than 30 days after the date of Substantial Performance of the Work. The Owner may retain out of the holdback amount any sums required by law to satisfy any legal hypothecs that have been taken or could be taken against the Work or other third party monetary claims against the Design -Builder which are enforceable against the Owner. GC 5.6 PROGRESSIVE RELEASE OF HOLDBACK In the Common Law provinces GC 5.6.1 shall read as follows: 5.6.1 Where legislation permits and where, upon application by the Design -Builder, the Consultant has certified that the work of a Subcontractor or Supplier has been performed prior to Substantial Performance of the Work, the Owner shall pay the Design -Builder the holdback amount retained for such subcontract work, or the Products supplied by such Supplier, on the day following the expiration of the holdback period for such work stipulated in the lien legislation applicable to the Place of the Work. 18 CCA-CSC-RAIC Document 14 — 2000 In the Province of Quebec GC 5.6.1 shall read as follows: 5.6.1 Where, upon application by the Design -Builder, the Consultant has certified that the work of a Subcontractor or Supplier has been performed prior to Substantial Performance of the Work, the Owner shall pay the Design -Builder the holdback amount retained for such subcontract work, or the Products supplied by such Supplier no later than 30 days after the date of Substantial Performance of the Work The Owner may retain out of the holdback amount any sums required to satisfy any legal hypothecs that have been taken or could be taken against the Work or other third party monetary claims against the Design -Builder which are enforceable against the Owner. 5.6.2 Notwithstanding the provisions of the preceding paragraph, and notwithstanding the wording of such certificates, the Design -Builder shall ensure that such subcontract work or Products is protected pending the issuance of a final certificate for payment and be responsible for the correction of defects or work not performed regardless of whether or not such was apparent when such certificates were issued. GC 5.7 FINAL PAYMENT 5.7.1 When the Design -Builder considers that the Work is completed, the Design -Builder shall submit an application for final payment and a certificate for payment issued by the Consultant to the Design -Builder in the amount applied for by the Design -Builder. 5.7.2 Unless the Payment Certifier is identified to be the Consultant, the Payment Certifier will review the Work to verify the validity of the application after the receipt of the Design -Builder's application for final payment and the Consultant's certificate for payment. The Payment Certifier will review the Work within 10 days of receipt of the Design -Builder's application and will issue to the Owner, no later than 7 days after reviewing the Work, a certificate for payment in the amount applied for or in such other amount as the Payment Certifier determines to be properly due. If the Payment Certifier amends the application, the Payment Certifier will promptly notify the Design -Builder in writing giving reasons for the amendment. 5.7.3 Subject to the provision of paragraph 10.4.1 of GC 10.4 - WORKERS' COMPENSATION, and any lien legislation applicable to the Place of the Work, the Owner shall make payment to the Design -Builder on account as provided in Article A-5 of the Agreement — PAYMENT no later than 15 days after the receipt of a final certificate for payment issued by the Payment Certifier. GC 5.8 WITHHOLDING OF PAYMENT 5.8.1 If because of climatic or other conditions reasonably beyond the control of the Design -Builder, there are items of the Work that cannot be performed, payment in full for that portion of the Work which has been performed as certified by the Payment Certifier shall not be withheld or delayed by the Owner on account thereof, but the Owner may withhold, until the remaining portion of the Work is finished, only such an amount that the Payment Certifier determines is sufficient and reasonable to cover the cost of performing such remaining work. GC 5.9 NON -CONFORMING WORK 5.9.1 No payment by the Owner under the Contract nor partial or entire use or occupancy of the Work by the Owner shall constitute an acceptance of any portion of the Work or Products which are not in accordance with the requirements of the Contract Documents. PART 6 CHANGES IN THE WORK GC 6.1 CHANGES 6.1.1 The Owner, without invalidating the Contract, may make changes in the Work consisting of additions, deletions, or other revisions to the Work by Change Order or Change Directive. 6.1.2 The Design -Builder shall not perform a change in the Work without a Change Order or a Change Directive except as provided in paragraph 6.1.6. 6.1.3 If a change in the Work results in a net increase in the Contract Price, an allowance for overhead and profit shall be included. 6.1.4 If a change in the Work results in a net decrease in the Contract Price, the amount of the credit shall be the net cost, without deduction for overhead or profit. CCA-CSC-RAIC Document 14 — 2000 19 6.1.5 When both additions and deletions covering related work or substitutions are involved in a change in the Work, the allowance for overhead and profit shall be calculated on the basis of the net increase, if any, with respect to that change in the Work. 6.1.6 The Design -Builder, without invalidating the Contract, may make minor adjustments in the Work consistent with the intent of the Contract Documents without a Change Order and shall advise the Owner in writing of such adjustments. Such adjustments in the Work shall not involve adjustment in the Contract Price or Contract Time. GC 6.2 CHANGE ORDER 6.2.1 When a change in the Work is proposed or required, the Owner or the Design -Builder shall provide a notice in writing describing the proposed change in the Work to the other party. The responding party shall present, in a form acceptable to the other party, an amendment to the Owner's Statement of Requirements, if any, and a method of adjustment or an amount of adjustment for the Contract Price, if any, and the adjustment in the Contract Time, if any, for the proposed change in the Work. 6.2.2 When the Owner and Design -Builder agree to the amendment to the Owner's Statement of Requirements, the adjustments in the Contract Price and Contract Time, or to the method to be used to determine the adjustments, such agreement shall be effective immediately and shall be recorded in a Change Order and signed by the Owner and Design -Builder. The value of the Work performed as the result of a Change Order shall be included in applications for progress payment. 6.2.3 If the Owner requests the Design -Builder to submit a proposal for a change in the Work and then elects not to proceed with the change, a Change Order shall be issued for the Owner to reimburse the Design -Builder for all costs incurred in any Design Services rendered. GC 6.3 CHANGE DIRECTIVE 6.3.1 If the Owner requires the Design -Builder to proceed with a change in the Work within the general scope of the Work prior to the Owner and the Design -Builder agreeing upon the adjustment in Contract Price and Contract Time, the Owner shall direct the preparation of a Change Directive. 6.3.2 Upon receipt of a Change Directive, the Design -Builder shall proceed promptly with the change in the Work. 6.3.3 The adjustment in the Contract Price for a change carried out by way of a Change Directive shall be determined on the basis of the cost of expenditures and savings to perform the work attributable to the change. 6.3.4 The Design -Builder shall keep and present, in such form as the Owner may require, an itemized accounting of the cost of expenditures and savings referred to in paragraph 6.3.3 together with supporting data. The cost of performing the work attributable to the Change Directive shall be limited to the actual cost of all of the following: .1 wages and benefits paid for labour in the direct employ of the Design -Builder under applicable collective bargaining agreements, or under a salary or wage schedule agreed upon by the Owner and Design -Builder; .2 salaries, wages, and benefits of the Design -Builder's personnel, when stationed at the field office, in whatever capacity employed; and personnel engaged at shops or on the road, in expediting the production or transportation of materials or equipment; .3 salaries, wages, and benefits of the Design -Builder's office personnel engaged in a technical capacity, and other personnel identified in the agreed wage schedule for the time spent in the performance of the Work; .4 contributions, assessments, or taxes incurred for such items as employment insurance, provincial health insurance, workers' compensation, and Canada or Quebec Pension Plan, insofar as such cost is based on wages, salaries, or other remuneration paid to employees of the Design -Builder and included in the cost of the work as provided in paragraphs 6.3.4.1, 6.3.4.2, and 6.3.4.3; .5 travel and subsistence expenses of the Design -Builder's personnel described in paragraphs 6.3.4.1, 6.3.4.2, and 6.3.4.3; .6 the cost of Design Services including all fees and disbursements of the Consultant or other consultants engaged or employed to provide such services; .7 the cost of all Products including cost of transportation thereof; .8 the cost of materials, supplies, equipment, temporary services and facilities, and hand tools not owned by the workers, including transportation and maintenance thereof, which are consumed; and cost less salvage value on such items used but not consumed, which remain the property of the Design -Builder; 20 CCA-CSC-RAIC Document 14 — 2000 .9 rental cost of all tools, machinery, and equipment, exclusive of hand tools, whether rented from or provided by the Design -Builder or others, including installation, minor repairs and replacements, dismantling, removal, transportation and delivery cost thereof; .10 deposits lost; .11 the amounts of all subcontracts; .12 the cost of quality assurance such as independent inspection and testing services; .13 charges levied by authorities having jurisdiction at the Place of the Work; .14 royalties, patent license fees, and damages for infringement of patents and cost of defending suits therefor subject always to the Design -Builder's obligations to indemnify the Owner as provided in paragraph 10.3.1 of GC 10.3 - PATENT FEES; .15 any adjustment in premium for all bonds and insurance which the Design -Builder is required, by the Contract Documents, to purchase and maintain in relation to the performance of the Work; .16 any adjustment in taxes and duties for which the Design -Builder is liable in relation to the performance of the Work; .17 charges for long distance telephone and facsimile communications, courier services, expressage, photocopying, reproduction of Contract Documents, and petty cash items incurred in relation to the performance of the Work; .18 the cost of removal and disposal of waste products and debris; .19 costs incurred due to emergencies affecting the safety of persons or property; 6.3.5 Pending determination of the final amount of a Change Directive, the undisputed value of the work performed as the result of a Change Directive is eligible to be included in progress payments. 6.3.6 If the Owner and Design -Builder do not agree on the proposed adjustment in the Contract Time or the method of determining it, the adjustment shall be referred to the Consultant for determination. 6.3.7 If at any time after the start of the Work directed by a Change Directive, the Owner and the Design -Builder reach agreement on the amendment to the Owner's Statement of Requirements or the adjustment to the Contract Price and to the Contract Time, this agreement shall be recorded in a Change Order signed by the Owner and the Design -Builder. GC 6.4 CONCEALED OR UNKNOWN CONDITIONS 6.4.1 If the Owner or the Design -Builder discover conditions at the Place of the Work which are: .1 subsurface or otherwise concealed physical conditions which existed before the commencement of the Work which differ materially from those indicated in the Contract Documents, or .2 physical conditions of a nature which differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, then the observing party shall notify the other party in writing, if possible before conditions are disturbed, and in no event later than 5 Working Days after first observance of the conditions. 6.4.2 The Consultant or other consultants will promptly investigate such conditions. The Consultant will notify the Owner and the Design -Builder of the finding in writing. If the finding is that the conditions differ materially and this would cause an increase or decrease in the Design -Builder's cost or time to perform the Work, the Owner shall issue appropriate instructions for a change in the Work as provided in GC 6.1 - CHANGES, GC 6.2 - CHANGE ORDER, and GC 6.3 - CHANGE DIRECTIVE. 6.4.3 If the Consultant finds that the conditions at the Place of the Work are not materially different or that no change in the Contract Price or the Contract Time is justified, the Consultant shall notify the Owner and Design -Builder in writing. GC 6.5 DELAYS 6.5.1 If the Design -Builder is delayed in the performance of the Work by an action or omission of the Owner or anyone employed or engaged by them directly or indirectly, contrary to the provisions of the Contract Documents, then the Contract Time shall be extended for such reasonable time as agreed between the Owner and the Design -Builder. Design -Builder shall be reimbursed by the Owner for reasonable costs incurred by the Design -Builder as the result of such delay. CCA-CSC-RAIC Document 14 — 2000 21 6.5.2 If the Design -Builder is delayed in the performance of the Work by a stop work order issued by a court or other public authority and providing that such order was not issued as the result of an act or fault of the Design -Builder or any person employed or engaged by the Design -Builder directly or indirectly, then the Contract Time shall be extended for such reasonable time as agreed between the Owner and the Design -Builder. The Design -Builder shall be reimbursed by the Owner for reasonable costs incurred by the Design -Builder as the result of such delay. 6.5.3 If the Design -Builder is delayed in the performance of the Work by labour disputes, strikes, lock -outs (including lock- outs decreed or recommended for its members by a recognized contractors' association, of which the Design -Builder is a member or to which the Design -Builder is otherwise bound), fire, unusual delay by common carriers or unavoidable casualties, or without limit to any of the foregoing, by a cause beyond the Design -Builder's control, then the Contract Time shall be extended for such reasonable time as agreed between the Owner and the Design -Builder. The extension of time shall not be less than the time lost as the result of the event causing the delay, unless the Design -Builder agrees to a shorter extension. The Design -Builder shall not be entitled to payment for costs incurred by such delays unless such delays result from actions by the Owner. 6.5.4 No extension shall be made for delay unless notice in writing of claim is given promptly to the Owner and in no event later than 10 Working Days after the commencement of delay, providing however, that in the case of a continuing cause of delay only one notice of claim shall be necessary. 6.5.5 Any adjustment to Contract Price and Contract Time required as a result of GC 6.5 - DELAYS shall be made as provided in GC 6.1 - CHANGES, GC 6.2 - CHANGE ORDER, and GC 6.3 - CHANGE DIRECTIVE. PART 7 DEFAULT NOTICE GC 7.1 OWNER'S RIGHT TO PERFORM THE WORK, SUSPEND THE WORK, OR TERMINATE THE CONTRACT 7.1.1 If the Design -Builder should be adjudged bankrupt, or makes a general assignment for the benefit of creditors because of the Design -Builder's insolvency, or if a receiver is appointed because of the Design -Builder's insolvency, the Owner may, without prejudice to any other right or remedy the Owner may have, by giving the Design -Builder or receiver or trustee in bankruptcy notice in writing, terminate the Design -Builder's right to continue with the Work. 7.1.2 If the Design -Builder should neglect to prosecute the Work properly or otherwise fails to comply with the requirements of the Contract to a substantial degree, the Owner may, without prejudice to any other right or remedy the Owner may have, notify the Design -Builder in writing that the Design -Builder is in default of the Design -Builder's contractual obligations and instruct the Design -Builder to correct the default in the 5 Working Days immediately following the receipt of such notice. 7.1.3 If the default cannot be corrected in the 5 Working Days specified, the Design -Builder shall be in compliance with the Owner's instructions if the Design -Builder: .1 commences the correction of the default within the specified time, and .2 provides the Owner with an acceptable schedule for such correction, and .3 corrects the default in accordance with such schedule. 7.1.4 If the Design -Builder fails to correct the default in the time specified or subsequently agreed upon, without prejudice to any other right or remedy the Owner may have, the Owner may: .1 correct such default and deduct the cost thereof from any payment then or thereafter due to the Design -Builder, or .2 terminate the Design -Builder's right to continue with the Work in whole or in part or terminate the Contract. 7.1.5 If the Owner terminates the Design -Builder's right to continue with the Work as provided in paragraphs 7. 1.1 and 7.1.4, the Owner shall be entitled to: .1 take possession of the Construction, and Products; utilize the Construction Documents, construction machinery, and equipment; subject to the rights of third parties, finish the Work by whatever reasonable method the Owner may consider expedient, but without undue delay or expense; .2 withhold further payment to the Design -Builder until a final certificate for payment is issued; .3 charge the Design -Builder the amount by which the full cost of finishing the Work and a reasonable allowance to cover the cost of corrections to Work performed by the Design -Builder that may be required under GC 12.3 - WARRANTY, exceeds the unpaid balance of the Contract Price; however, if such cost of finishing the Work is less than the unpaid balance of the Contract Price, the Owner shall pay the Design -Builder the difference; and 22 CCA-CSC-RAIC Document 14 — 2000 .4 on expiry of the warranty period, charge the Design -Builder the amount by which the cost of corrections to the Design -Builders work under GC 12.3 - WARRANTY exceeds the allowance provided for such corrections, or if the cost of such corrections is less than the allowance, pay the Design -Builder the difference. 7.1.6 The Design -Builder's obligation under the Contract as to quality, correction, and warranty of the work performed by the Design -Builder up to the time of termination shall continue in force after such termination. 7.1.7 The Owner may, if conditions arise which make it necessary for reasons other than as provided in paragraphs 7. 1.1 and 7.1.4, suspend performance of the Work or terminate the Contract by giving written notice to that effect to the Design -Builder identifying the reason for the suspension and the expected length of the suspension. Such suspension or termination shall be effective in the manner specified in said notice and shall be without prejudice to any claims which either party may have against the other. 7.1.8 The Design -Builder upon receiving notice of suspension or termination from the Owner shall suspend all operations as soon as reasonably possible except Work which, in the Design -Builder's opinion, is necessary for the safety of personnel and for the care and preservation of the Work, the materials and plant. Subject to any directions in the notice of suspension or termination, the Design -Builder shall discontinue ordering materials, facilities, and supplies and make every reasonable effort to delay delivery of existing orders and, in the event of termination, to cancel existing orders on the best terms available. 7.1.9 During the period of suspension, the Design -Builder shall not remove from the site any part of the Work, or any Product or materials without the consent of the Owner. 7. l .10 If the Work should be suspended for a period of 30 days or less, the Design -Builder, upon the expiration of the period of suspension, shall resume the performance of the Work in accordance with the Contract Documents. If the suspension was not due to an act or an omission of the Design -Builder, the Contract Price and Contract Time shall be adjusted as provided in paragraph 6.5.1 of GC 6.5 - DELAYS. 7. l .11 If, after 30 days from the date of notice of suspension of the Work the Owner and the Design -Builder agree to continue with and complete the Work, the Design -Builder shall resume operations and complete the Work in accordance with any terms and conditions agreed upon by the Owner and the Design -Builder. GC 7.2 DESIGN -BUILDER'S RIGHT TO SUSPEND THE WORK OR TERMINATE THE CONTRACT 7.2.1 If the Owner should be adjudged bankrupt, or makes a general assignment for the benefit of creditors because of the Owner's insolvency, or if a receiver is appointed because of the Owner's insolvency, the Design -Builder may, without prejudice to any other right or remedy the Design -Builder may have, by giving the Owner or receiver or trustee in bankruptcy notice in writing, terminate the Contract. 7.2.2 If the Work should be suspended or otherwise delayed for a period of 30 days or more under the Owner's direction as provided in paragraph 7.1.7 of GC 7.1 - OWNER'S RIGHT TO PERFORM THE WORK, SUSPEND THE WORK, OR TERMINATE THE CONTRACT or under an order of a court or other public authority and providing that such order was not issued as the result of an act or fault of the Design -Builder or of anyone directly or indirectly employed or engaged by the Design -Builder, the Design -Builder may, without prejudice to any other right or remedy the Design -Builder may have, by giving the Owner notice in writing, terminate the Contract. 7.2.3 The Design -Builder may notify the Owner in writing that the Owner is in default of the Owner's contractual obligations if: .1 the Owner fails to furnish, when so requested by the Design -Builder, reasonable evidence that financial arrangements have been made to fulfil the Owner's obligations under the Contract, .2 the Owner fails to pay the Design -Builder the amounts due under the Contract or awarded by arbitration or court, .3 the Owner has made an assignment of the Contract without the required consent of the Design -Builder, or .4 the Owner persistently disregards communications or reasonable requests from the Design -Builder for information or instructions, or otherwise violates the requirements of the Contract to a substantial degree. 7.2.4 The Design -Builder's notice in writing to the Owner provided under paragraph 7.2.3 shall advise that if the default is not corrected within 5 Working Days following the receipt of the notice, the Design -Builder may, without prejudice to any other right or remedy the Design -Builder may have, suspend the Work or terminate the Contract. CCA-CSC-RAIC Document 14 — 2000 23 7.2.5 If the Design -Builder terminates the Contract under the conditions set out above, the Design -Builder shall be entitled to be paid for all Work performed including reasonable profit, for loss sustained upon Products and construction machinery and equipment, and such other damages as the Design -Builder may have sustained as a result of the termination of the Contract. PART 8 DISPUTE RESOLUTION GC 8.1 AUTHORITY OF THE CONSULTANT 8.1.1 Differences between the parties to the Contract as to the interpretation, application, or administration of the Contract or any failure to agree where agreement between the parties is called for, collectively referred to as disputes, which are not resolved in the first instance by findings of the Consultant as provided in GC 2.1 - CONSULTANT, shall be settled in accordance with the requirements of Part 8 of the General Conditions - DISPUTE RESOLUTION. 8.1.2 If a dispute is not resolved promptly, the Consultant shall give such written instructions as in the Consultant's opinion are necessary for the proper performance of the Work and to prevent delays pending settlement of the dispute. The Design -Builder shall act immediately according to such instructions, it being understood that by so doing the Design - Builder will not jeopardize any claim the Design -Builder may have. If it is subsequently determined that such instructions were in error or at variance with the Contract Documents, the Owner shall pay the Design -Builder costs incurred by the Design -Builder in carrying out such instructions which the Design -Builder was required to do beyond what the Contract Documents correctly understood and interpreted would have required, including costs resulting from interruption of the Work. GC 8.2 NEGOTIATION, MEDIATION, AND ARBITRATION 8.2.1 In accordance with the latest edition of the Rules for Mediation of Construction Disputes as provided in CCDC 40, the parties shall appoint a Project Mediator . l within 30 days after the Contract was awarded, or .2 if the parties neglected to make an appointment within the 30 day period, within 15 days after either party by notice in writing requests that the Project Mediator be appointed. 8.2.2 A party shall be conclusively deemed to have accepted a finding of the Consultant under GC 2.1 - CONSULTANT and to have expressly waived and released the other party from any claims in respect of the particular matter dealt with in that finding unless, within 15 Working Days after receipt of that finding, the party sends a notice in writing of dispute to the other party and to the Consultant, which contains the particulars of the matter in dispute and the relevant provisions of the Contract Documents. The responding party shall send a notice in writing of reply to the dispute within 10 Working Days after receipt of the notice of dispute setting out particulars of this response and any relevant provisions of the Contract Documents. 8.2.3 The parties shall make all reasonable efforts to resolve their disputes by amicable negotiations and agree to provide, without prejudice, frank, candid, and timely disclosure of relevant facts, information, and documents to facilitate these negotiations. 8.2.4 After a period of 10 Working Days following receipt of a responding party's notice in writing of reply under paragraph 8.2.2, the parties shall request the Project Mediator to assist the parties to reach agreement on any unresolved dispute. The mediated negotiations shall be conducted in accordance with the latest edition of the Rules for Mediation of Construction Disputes as provided in CCDC 40. 8.2.5 If the dispute has not been resolved within 10 Working Days after the Project Mediator was requested under paragraph 8.2.4 or within such further period agreed by the parties, the Project Mediator shall terminate the mediated negotiations by giving notice in writing to both parties. 8.2.6 By giving a notice in writing to the other party, not later than 10 Working Days after the date of termination of the mediated negotiations under paragraph 8.2.5, either party may refer the dispute to be finally resolved by arbitration under the latest edition of the Rules for Arbitration of Construction Disputes as provided in CCDC 40. The arbitration shall be conducted in the jurisdiction of the Place of the Work. 8.2.7 On expiration of the 10 Working Days, the arbitration agreement under paragraph 8.2.6 is not binding on the parties and, if a notice is not given under paragraph 8.2.6 within the required time, the parties may refer the unresolved dispute to the courts or to any other form of dispute resolution, including arbitration, which they have agreed to use. 24 CCA-CSC-RAIC Document 14 — 2000 8.2.8 If neither party requires by notice in writing given within 10 Working Days of the date of notice requesting arbitration in paragraph 8.2.6 that a dispute be arbitrated immediately, all disputes referred to arbitration as provided in paragraph 8.2.6 shall be .1 held in abeyance until (1) Substantial Performance of the Work, (2) the Contract has been terminated, or (3) the Design -Builder has abandoned the Work, whichever is earlier, and .2 consolidated into a single arbitration under the rules governing the arbitration under paragraph 8.2.6. GC 8.3 RETENTION OF RIGHTS 8.3.1 It is agreed that no act by either party shall be construed as a renunciation or waiver of any rights or recourses, provided the party has given the notices required under Part 8 of the General Conditions - DISPUTE RESOLUTION and has carried out the instructions as provided in paragraph 8.1.2. 8.3.2 Nothing in Part 8 of the General Conditions - DISPUTE RESOLUTION shall be construed in any way to limit a party from asserting any statutory right to a lien under applicable lien legislation of the jurisdiction of the Place of the Work and the assertion of such right by initiating judicial proceedings is not to be construed as a waiver of any right that party may have under paragraph 8.2.6 to proceed by way of arbitration to adjudicate the merits of the claim upon which such a lien is based. PART 9 PROTECTION OF PERSONS AND PROPERTY GC 9.1 PROTECTION OF WORK AND PROPERTY 9.1.1 The Design -Builder shall protect the Work and the Owner's property and property adjacent to the Place of the Work from damage which may arise as the result of the Design -Builder's operations under the Contract, and shall be responsible for such damage, except damage which occurs as the result of: .1 errors in the Contract Documents issued by the Owner, .2 acts or omissions by the Owner, other contractors, their agents and employees. 9.1.2 Should the Design -Builder in the performance of the Contract damage the Work, the Owner's property, or property adjacent to the Place of the Work, the Design -Builder shall be responsible for the making good such damage at the Design -Builder's expense. 9.1.3 Should damage occur to the Work or Owner's property for which the Design -Builder is not responsible, as provided in paragraph 9.1.1, the Design -Builder shall at the Owner's expense make good such damage to the Work and, if the Owner so directs, to the Owner's property. The Contract Price and Contract Time shall be adjusted as provided in GC 6.1 - CHANGES, GC 6.2 - CHANGE ORDER, and GC 6.3 - CHANGE DIRECTIVE. GC 9.2 DAMAGES AND MUTUAL RESPONSIBILITY 9.2.1 If either party to the Contract should suffer damage in any manner because of any wrongful act or neglect of the other party or of anyone for whom the other party is responsible in law, then that party shall be reimbursed by the other party for such damage. The reimbursing party shall be subrogated to the rights of the other party in respect of such wrongful act or neglect if it be that of a third party. 9.2.2 Claims for damage under paragraph 9.2.1 shall be made in writing to the party liable within reasonable time after the first observance of such damage and if undisputed shall be confirmed by Change Order. Disputed claims shall be resolved as set out in Part 8 of the General Conditions - DISPUTE RESOLUTION. 9.2.3 If the Design -Builder has caused damage to the work of another contractor on the Project, the Design -Builder agrees upon due notice to settle with the other contractor by negotiation or arbitration. If the other contractor makes a claim against the Owner on account of damage alleged to have been so sustained, the Owner shall notify the Design -Builder and may require the Design -Builder to defend the action at the Design -Builder's expense. The Design -Builder shall satisfy a final order or judgment against the Owner and pay the costs incurred by the Owner arising from such action. 9.2.4 If the Design -Builder becomes liable to pay or satisfy a final order, judgment, or award against the Owner, then the Design -Builder, upon undertaking to indemnify the Owner against any and all liability for costs, shall have the right to appeal in the name of the Owner such final order or judgment to any and all courts of competent jurisdiction. CCA-CSC-RAIC Document 14 — 2000 25 GC 9.3 TOXIC AND HAZARDOUS SUBSTANCES AND MATERIALS 9.3.1 For the purposes of applicable environmental legislation, the Owner shall be deemed to have control and management of the Place of the Work with respect to existing conditions. 9.3.2 Prior to the Design -Builder commencing the Work, the Owner shall .1 take all reasonable steps to determine whether any toxic or hazardous substances or materials are present at the Place of the Work, and .2 provide the Design -Builder with a written list of any such substances and materials. 9.3.3 The Owner shall take all reasonable steps to ensure that no person suffers injury, sickness, or death and that no property is injured, damaged, or destroyed as a result of exposure to, or the presence of, toxic or hazardous substances or materials which were at the Place of the Work prior to the Design -Builder commencing the Work. 9.3.4 Unless the Contract Documents expressly provides otherwise, the Owner shall be responsible for taking all necessary steps, in accordance with legal requirements, to dispose of, store or otherwise render harmless, toxic or hazardous substances or materials which were present at the Place of the Work prior to the Design -Builder commencing the Work. 9.3.5 If the Design -Builder .1 encounters toxic or hazardous substances or materials at the Place of the Work, or .2 has reasonable grounds to believe that toxic or hazardous substances or materials are present at the Place of the Work, which were not disclosed by the Owner, as required under paragraph 9.3.2, or which were disclosed but have not been dealt with as required under paragraph 9.3.4, the Design -Builder shall .3 take all reasonable steps, including stopping the Work, to ensure that no person suffers injury, sickness, or death and that no property is injured or destroyed as a result of exposure to or the presence of the substances or materials, and .4 immediately report the circumstances to the Owner in writing. 9.3.6 If the Design -Builder is delayed in performing the Work or incurs additional costs as a result of taking steps required under paragraph 9.3.5.3, the Contract Time shall be extended and the Design -Builder shall be reimbursed for all reasonable costs incurred as a result of the delay and as a result of taking those steps. 9.3.7 The Owner and the Design -Builder may jointly rely upon the advice of an independent expert in a dispute under paragraph 9.3.6 and, in that case, the expert shall be jointly selected, retained, and paid by the Owner and the Design - Builder. 9.3.8 The Owner shall indemnify and hold harmless the Design -Builder, Consultant, other consultants, Subcontractors, Suppliers, and their agents and employees, from and against claims, demands, losses, costs, damages, actions, suits, or proceedings arising out of or resulting from exposure to, or the presence of, toxic or hazardous substances or materials which were at the Place of the Work prior to the Design -Builder commencing the Work. This obligation shall not be construed to negate, abridge, or reduce other rights or obligations of indemnity set out in GC 12.1 - INDEMNIFICATION or which otherwise exist respecting a person or party described in this paragraph. 9.3.9 GC 9.3 - TOXIC AND HAZARDOUS SUBSTANCES AND MATERIALS shall govern over the provisions of paragraph 1.4.1 of GC 1.4 - RIGHTS AND REMEDIES or GC 9.2 - DAMAGES AND MUTUAL RESPONSIBILITY. PART 10 GOVERNING REGULATIONS GC 10.1 TAXES AND DUTIES 10.1.1 The Contract Price shall include all taxes and customs duties in effect at the time of the proposal or bid closing except for Value Added Taxes payable by the Owner to the Design -Builder as stipulated in Article A-4 of the Agreement - CONTRACT PRICE. 10.1.2 Any increase or decrease in costs to the Design -Builder due to changes in such included taxes and duties after the time of the proposal or bid closing, as the case may be, shall increase or decrease the Contract Price accordingly. 10.1.3 Refunds that are properly due to the Owner and have been recovered by the Design -Builder will be promptly refunded to the Owner. 26 CCA-CSC-RAIC Document 14 — 2000 GC 10.2 LAWS, NOTICES, PERMITS, AND FEES 10.2.1 The Owner shall obtain and pay for the permanent easements and rights of servitude. 10.2.2 Unless otherwise stated, the Design -Builder shall obtain and pay for the building permit and other permits, licences, or certificates necessary for the performance of the Work which were in force at the time of the proposal or bid closing. 10.2.3 The Design -Builder shall give the required notices and comply with the laws, ordinances, rules, regulations, or codes which are or become in force during the performance of the Work and which relate to the Work, to the preservation of the public health, and to construction safety. 10.2.4 The Design -Builder shall not be responsible for verifying that the Owner's Statement of Requirements is in substantial compliance with the applicable laws, ordinances, rules, regulations, or codes relating to the Work. If, after the time of the proposal or bid closing, changes are made to the applicable laws, ordinances, rules, regulations, or codes which require modification to the Contract Documents, the Design -Builder shall notify the Owner in writing requesting direction immediately upon such variance or change becoming known. Changes shall be made as provided in GC 6.1 - CHANGES, GC 6.2 - CHANGE ORDER, and GC 6.3 - CHANGE DIRECTIVE. 10.2.5 If the Design -Builder fails to notify the Owner in writing, fails to obtain direction as required in paragraph 10.2.4, and performs work knowing it to be contrary to any laws, ordinances, rules, regulations, or codes; the Design -Builder shall be responsible for and shall correct the violations thereof; and shall bear the costs, expenses, and damages attributable to the failure to comply with the provisions of such laws, ordinances, rules, regulations, or codes. GC 10.3 PATENT FEES 10.3.1 The Design -Builder shall pay the royalties and patent licence fees required for the performance of the Contract. The Design -Builder shall hold the Owner harmless from and against claims, demands, losses, costs, damages, actions, suits, or proceedings arising out of the Design -Builder's performance of the Contract which are attributable to an infringement or an alleged infringement of a patent of invention by the Design -Builder or anyone for whose acts the Design -Builder may be liable. 10.3.2 The Owner shall hold the Design -Builder harmless against claims, demands, losses, costs, damages, actions, suits, or proceedings arising out of the Design -Builder's performance of the Contract which are attributable to an infringement or an alleged infringement of a patent of invention in executing anything for the purpose of the Contract, the model, plan, or design of which was supplied to the Design -Builder as part of the Contract Documents. GC 10.4 WORKERS' COMPENSATION 10.4.1 Prior to commencing the Work, Substantial Performance of the Work, and the application for final payment, the Design -Builder shall provide evidence of compliance with workers' compensation legislation at the Place of the Work, including payments due under it. 10.4.2 At any time during the term of the Contract, when requested by the Owner, the Design -Builder shall provide such evidence of compliance by the Design -Builder and Subcontractors and any other person performing the Work who is required to comply with such legislation. PART 11 INSURANCE BONDS GC 11.1 INSURANCE 11.1.1 Without restricting the generality of GC 12.1 - INDEMNIFICATION, and unless the Owner and the Design -Builder agree to obtain project -specific insurance, or higher insurance limits, the Design -Builder shall provide, maintain, and pay for the minimum insurance coverages specified in GC 11.1 - INSURANCE. .1 General Liability Insurance: The policy shall be in the joint names of the Design -Builder, the Owner, the Consultant and other consultants, with limits of not less than $2,000,000 per occurrence and with a property damage deductible of not more than $51,000. The insurance coverage shall not be less than the insurance required by IBC Forms 2100 and 2320, or their equivalent replacement. Umbrella or excess liability insurance may be used to achieve the desired limit. Where the Design -Builder maintains a single, blanket policy, the addition of the Owner is limited to liability arising out of the Work and all operations necessary or incidental thereto. CCA -CSC -RAIL Document 14-2000 27 Completed Operations Liability coverage shall be maintained continuously from the commencement of the Construction until two years after Substantial Performance of the Work. .2 Errors and Omissions Insurance: The Design -Builder shall ensure that the Consultant and other consultants engaged in the performance of the Design Services each carry Errors and Omissions Insurance that have limits of not less than $250,000 per claim and with an aggregate limit of not less than $500,000 within any policy year. The Consultant or other consultants found to be at fault will be responsible for the deductible amount. The policy shall be maintained continuously from the commencement of the Work, until 2 years after Substantial Performance of the Work. .3 Automobile Liability Insurance: The policy covers for bodily injury, death, and damage to property with respect to all licensed vehicles owned or leased by the Design -Builder. The policy shall have limits of not less than $2,000,000 inclusive per occurrence. If the policy is issued pursuant to a government -operated automobile insurance system, the Design -Builder shall provide the Owner with confirmation of automobile insurance coverage for all automobiles registered in the name of the Design -Builder. .4 Aircraft and Watercraft Liability Insurance: The policy shall be for owned or non -owned aircraft and watercraft used directly or indirectly by the Design - Builder in the performance of the Work, including use of additional premises. The policy shall have limits of not less than $2,000,000 inclusive per occurrence for bodily injury, death, and damage to property including loss of use thereof and limits of not less than $2,000,000 for aircraft passenger hazard. .5 Property and Boiler and Machinery Insurance: (1) "All risks" property insurance shall be in the joint names of the Design -Builder, the Owner, the Consultant, all other consultants, and all Subcontractors. The insurance coverage shall not be less than the insurance required by IBC Forms 4042 and 4047, or their equivalent replacement. The insurance provided shall have limits of not less than the sum of the amount of the Contract Price, the applicable Value Added Taxes, and the full value of products provided by the owner for incorporation into the Work as specified in the Supplementary Conditions. The policy shall have a deductible of not more than $10,000. (2) Boiler and machinery insurance shall be in the joint names of the Design -Builder, the Owner, the Consultant, all consultants, and all Subcontractors. The insurance coverage shall not be less than the insurance provided by the "Comprehensive Boiler and Machinery Form". The insurance provided shall have limits of not less than the replacement value of the boilers, pressure vessels, and other insurable objects forming part of the Work. (3) The policies shall allow for partial or total use or occupancy of the Work. If because of such use or occupancy the Design -Builder is unable to provide coverage, the Design -Builder shall notify the owner in writing. Prior to such use or occupancy, the Owner shall provide, maintain, and pay for all risk property and boiler insurance in the amounts described in sub -paragraphs (1) and (2), including coverage for such use or occupancy and shall provide the Design -Builder with proof of such insurance. The policies shall be amended to include permission for completion of Construction and shall include all insureds as specified in sub- paragraph (1). The Design -Builder shall refund to the owner the unearned premiums applicable to the Design -Builder's policies upon termination of coverage. (4) The policies shall provide that, in the case of a loss or damage, payment shall be made to the Owner and the Design -Builder as their respective interests may appear. The Design -Builder shall act on behalf of the Owner for the purpose of adjusting the amount of such loss or damage payment with the insurers. When the extent of the loss or damage is determined, the Design -Builder shall proceed to restore the Work. Loss or damage shall not affect the rights and obligations of either party under the Contract except that the Design -Builder shall be entitled to a reasonable extension of Contract Time. (5) The Design -Builder shall be entitled to receive from the Owner, in addition to the amount due under the Contract, the amount at which the Owner's interest in restoration of the Work has been appraised, such amount to be paid as the restoration of the Work proceeds and as provided in GC 5.2 - APPLICATIONS FOR PROGRESS PAYMENT and GC 5.3 - PROGRESS PAYMENT. In addition the Design -Builder shall be entitled to receive from the payments made by the insurer the amount of the Design -Builder's interest in the restoration of the Work. 28 CCA-CSC-RAIC Document 14 — 2000 (6) In the case of loss or damage to the Work arising from the work of another contractor, or Owner's own forces, the Owner, in accordance with the Owner's obligations under paragraph 3.3.2.4 of GC 3.3 - CON STRUCTION BY OWNER OR OTHER CONTRACTORS, shall pay the Design -Builder the cost of restoring the Work as the restoration of the Work proceeds and as provided in GC 5.2 - APPLICATIONS FOR PROGRESS PAYMENT and GC 5.3 - PROGRESS PAYMENT. .6 Equipment Insurance: The policy covers construction machinery and equipment used by the Design -Builder for the performance of the Work, including boiler insurance on temporary boilers and pressure vessels. The policy shall be in a form acceptable to the Owner and shall not allow subrogation claims by the insurer against the Owner. Subject to satisfactory proof of financial capability by the Design -Builder for self-insurance, the Owner agrees to waive the equipment insurance requirement. 11.1.2 Unless otherwise stipulated, the duration of each insurance policy shall be from the date of commencement of the Work until the date of the final certificate for payment. 11.1.3 The Design -Builder shall be responsible for deductible amounts under the policies except where otherwise provided in GC 11.1 - INSURANCE or where such amounts may be excluded from the Design -Builder's responsibility by the terms of GC 9.1 - PROTECTION OF WORK AND PROPERTY and GC 9.2 - DAMAGES AND MUTUAL RESPONSIBILITY. 11. 1.4 Prior to commencement of the Work and upon the placement, renewal, amendment, or extension of all or any part of the insurance, the Design -Builder shall promptly provide the Owner with confirmation of coverage and, if required, a certified true copy of the policies certified by an authorized representative of the insurer together with copies of any amending endorsements. 11.1.5 Where the full insurable value of the Work is substantially less than the Contract Price, the Owner may reduce the amount of insurance required or waive the Property and Boiler and Machinery Insurance requirement. 11.1.6 If the Design -Builder fails to provide or maintain insurance as required by the Contract Documents, then the Owner shall have the right to provide and maintain such insurance and give evidence to the Design -Builder and the Consultant. The Design -Builder shall pay the cost thereof to the Owner on demand or the Owner may deduct the amount which is due or may become due to the Design -Builder. 11.1.7 All required insurance policies shall be placed with insurers licensed to underwrite insurance in the jurisdiction of the Place of the Work. 11.1.8 All required insurance policies shall be endorsed to provide the Owner with not less than 30 days notice in writing in advance of any cancellation and material amendment or change restricting coverage. 11.1.9 All insureds shall cooperate with the .Design -Builder to comply with any reporting requirements of the insurance policies in order to maintain the policies in good standing, to give notice in writing of any incidents which may result in a claim or loss covered by the policies and to provide documentation necessary in the defence or settlement of claims. GC 11.2 BONDS 11.2.1 The Design -Builder shall, prior to commencement of the Work or within the time specified in the Contract, provide to the Owner such surety bonds as are required by the Contract Documents. 11.2.2 Such bonds shall be issued by a duly licensed surety company authorized to transact a business of suretyship in the province or territory of the Place of the Work and shall be maintained in good standing until the fulfilment of the Contract. The surety bonds shall be in accordance with the latest edition of the CCDC approved bond forms. CCA -CSC -RAIL Document 14 — 2000 29 PART 12 INDEMNIFICATION WAIVER WARRANTY GC 12.1 INDEMNIFICATION 12.1.1 The Design -Builder shall indemnify and hold harmless the Owner, the Owner's agents and employees from and against claims, demands, losses, costs, damages, actions, suits, or proceedings (hereinafter called "claims"), by third parties that arise out of, or are attributable to, the Design -Builder's performance of the Work, provided such claims are: .1 attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property, and .2 caused by negligent acts or omissions of the Design -Builder, the Consultant, all other consultants, all Subcontractors or anyone for whose acts the Design -Builder may be liable, and .3 made in writing within a period of 2 years from the date of Substantial Performance of the Work or within such shorter period as may be prescribed by any limitation statute of the province or territory of the Place of the Work. The Owner expressly waives the right to indemnity for claims other than those stated above. 12.1.2 The obligation of the Design -Builder to indemnify under this Contract shall be limited to the insurance coverages and limits as agreed to be provided in GC 11.1 - INSURANCE. 12.1.3 The Owner shall indemnify and hold harmless the Design -Builder, the Consultant, all other consultants, all Subcontractors, all Suppliers, their agents and employees from and against claims, demands, losses, costs, damages, actions, suits, or proceedings arising out of the Design -Builder's performance of the Design Services and Construction, which are attributable to a lack of or defect in title or an alleged lack of or defect in title to the Place of the Work or a negligent act or omission or wilful default of the Owner, its agents and employees or any other person in respect of those acts the Owner may be liable. 12.1.4 GC 12.1 - INDEMNIFICATION shall govern over the provisions of paragraph 1.4.1 of GC 1.4 - RIGHTS AND REMEDIES or GC 9.2 - DAMAGES AND MUTUAL RESPONSIBILITY. GC 12.2 WAIVER OF CLAIMS 12.2.1 Waiver of Claims by Owner As of the date of the final certificate for payment, the Owner expressly waives and releases the Design -Builder, the Consultant, all other consultants, all Subcontractors, all Suppliers, and their agents and employees from all claims against them including without limitation those that might arise from the negligence or breach of contract by the Design -Builder, the Consultant, all other consultants, all Subcontractors, and their agents and employees except one or more of the following: .1 those made in writing prior to the date of the final certificate for payment and still unsettled; .2 those arising from the provisions of GC 12.1 - INDEMNIFICATION or GC 12.3 - WARRANTY; .3 those arising from the provisions of paragraph 9.3.5 of GC 9.3 - TOXIC AND HAZARDOUS SUBSTANCES AND MATERIALS and arising from the Design -Builder bringing or introducing any toxic or hazardous substances and materials to the Place of the Work after the Design -Builder commences the Work. In the Common Law provinces GC 12.2.1.4 shall read as follows: .4 those made in writing within a period of 2 years from the date of Substantial Performance of the Work or within such shorter period as may be prescribed by any limitation statute of the province or territory of the Place of the Work and arising from any liability of the Design -Builder for damages resulting from the Design -Builder's performance of the Contract with respect to substantial defects or deficiencies in the Work for which the Design - Builder is proven responsible. As used herein "substantial defects or deficiencies" means those defects or deficiencies in the Construction which affect the Work to such an extent or in such a manner that a significant part or the whole of the Construction is unfit for the purpose specified in the Contract Documents. In the Province of Quebec GC 12.2.1.4 shall read as follows: .4 those arising under the provisions of Article 2118 of the Civil Code of Quebec. 12.2.2 Waiver of Claims by Design -Builder As of the date of the final certificate for payment, the Design -Builder expressly waives and releases the Owner from all claims against the Owner including without limitation those that might arise from the negligence or breach of contract by the Owner except: .1 those made in writing prior to the Design -Builder's application for final payment and still unsettled; and .2 those arising from the provisions of GC 9.3 - TOXIC AND HAZARDOUS SUBSTANCES AND MATERIALS or GC 10.3 - PATENT FEES. 30 CCA-CSC-RAIC Document 14 — 2000 12.2.3 GC 12.2 - WAIVER OF CLAIMS shall govern over the provisions of paragraph 1.4.1 of GC 1.4 - RIGHTS AND REMEDIES or GC 9.2 - DAMAGES AND MUTUAL RESPONSIBILITY. GC 12.3 WARRANTY 12.3.1 The warranty period with regard to the Contract is one year from the date of Substantial Performance of the Work or such other periods specified in the Contract Documents for certain portions of the Work or Products. 12.3.2 The Design -Builder warrants that the Design Services meet the standard described in GC 2.1.4. and that the Work is in accordance with the Contract Documents. 12.3.3 Except for the provisions of paragraphs 12.3.2 and 12.3.6, the Design -Builder shall correct promptly, at the Design - Builders expense, any work which is not in accordance with the Contract Documents or defects or deficiencies in the Work which appear prior to and during the warranty periods specified in the Contract Documents. 12.3.4 The owner shall promptly give the Design -Builder notice in writing of observed defects and deficiencies that occur during the warranty period. 12.3.5 The Design -Builder shall correct or pay for damage resulting from the defects or deficiencies and the corrections made under the requirements of paragraph 12.3.3. 12.3.6 The Design -Builder shall be responsible for obtaining Product warranties in excess of one year on behalf of the Owner from the manufacturer. These Product warranties shall be issued by the manufacturer to the benefit of the Owner. 12.3.7 The Design -Builder does not warrant against the effects of corrosion, erosion or wear and tear of any Product or failure of any Product due to faulty operations or maintenance by the Owner or conditions of operation more severe than those specified for the Product. 12.3.8 The warranties and guarantees specified in GC 12.3 - WARRANTY or elsewhere in the Contract Documents are the only warranties and guarantees of the Design -Builder applicable to the Work and no other warranties or guarantees, statutory or otherwise, are or will be implied. CCA -CSC -RAIL Document 14 — 2000 31 Appendix A Contract Work Schedule GATEMAN` MILLOY January 21, 2008 Town of Tillsonburg Community Trail Development Contract Work Schedule 1. Design — 23,300.00 Creation of trail master plan, construction drawings including associated details and reviews. Also includes construction plan for works within Otter Creek at 3rd bridge location as per LPRCA. 2. Contract Administration — 20,000.00 MBTW Group to review construction progress including review and certification of Gateman Milloy invoices on behalf of the Town to ensure the trail is constructed in accordance with the plans and specifications. 3. Pedestrian Bridges — 227,014.61 Supply and install 3 pedestrian bridges at 2.4m width complete with concrete abutments. Bridges to be self - weathering steel including railings and wooden deck. 4. John Pound Tunnel Crossing —178,085.85 Supply and install pre -cast box culvert in accordance with Philips Engineering's drawing submitted to the County of Oxford including associated armourstone retaining walls and restoration. 5. West Golf Trail Section (2,200m) - 218,692.63 Clear & grub for trail construction Dispose of stumps on-site Supply and install silt control fencing including removal upon grow -in Topsoil stripping & rough grading to sub -grade Supply & installation of 150mm depth @ 3m width granular A (2,280 tonnes) Supply & installation of 50mm depth @ 2.8m width limestone screenings (380 tonnes) Supply & installation of 50mm HU asphalt paving @ 2.8m width on slopes and high traffic areas (2,870 sq.m) Supply & installation of 7 pvc N 12 culverts @ 6m length Topsoil pathway edges to finished grades Hydroseed pathway edges @ 1 m each side with bluegrass or fescue seed mix (2,200 sq.m) Supply & install bluegrass sod along pathway edges @ 1 m each side in slope and high traffic areas (2,200 sq.m) Supply & install 30 tonnes of armourstone on slopes to direct public traffic Supply & install 30 trees @ 250cm ht to screen golf holes from public traffic Supply & install 7 information signs 270 Shoemaker Street •Kitchener, Ontario • N2E 3E1 • 519 748 6500. 748 6626 6. East Golf Trail Section (1,100m) - 157,400.51 Clear & grub for trail construction Dispose of stumps on and off-site Supply and install silt control fencing including removal upon grow -in Topsoil stripping & rough grading to sub -grade Supply & installation of 150mm depth @ 3m width granular A (1,140 tonnes) Supply & installation of 50mm depth @ 2.8m width limestone screenings (115 tonnes) Supply & installation of 50mm HU asphalt paving @ 2.8m width on slopes and high traffic areas (2,086 sq.m) Supply & installation of 4 pvc N12 culverts @ 6m length Topsoil pathway edges to finished grades Hydroseed pathway edges @ 1 m each side with bluegrass or fescue seed mix (7 10 sq.m) Supply and install bluegrass sod along pathway edges @ 1 m each side in slope and high traffic areas (1,490 sq.m) Supply & install 60 tonnes of armourstone on slopes to direct public traffic Supply & install 37 trees @ 250cm ht to screen golf holes from public traffic Supply & install 8 information signs 7. Coronation Trail Section (480m) - 50,477.32 Clear & grub for trail construction Dispose of stumps off-site Supply and install silt control fencing including removal upon grow -in Topsoil stripping & rough grading to sub -grade Supply & installation of 150mm depth @ 3m width granular A (500 tonnes) Supply & installation of 50mm depth @ 2.8m width limestone screenings (155 tonnes) Supply & installation of 3 pvc N12 culverts @ 6m length Topsoil pathway edges to finished grades Hydroseed pathway edges @ 1 m each side with bluegrass or fescue seed mix (960 sq.m) Supply & install 10 tonnes of armourstone on slopes to direct public traffic Supply & install 1 information sign 8. Borden Cres Trail Section (1,130m) — Not Included 9. Creek Enhancement Works (as per LPRCA) — 60,205.36 Remove and dispose of debris from behind existing bridge abutment within Otter Creek Supply and install temporary creek diversion including dewatering in order for equipment to enter dry creek Remove and dispose of existing abutment within Otter Creek Supply and install 25-150mm riffle section (round stone) in Otter Creek at maximum 200mm depth. Riffle section to be approximately 30 x 30m (400 tonnes) Remove temporary creek diversion Supply and install 50-150mm rip -rap complete with topsoil to re-stablilize creek banks at bridge locations (300 tonnes). Supply and install bare -root shrubs within rip -rap to increase bank and soil stability Supply and install 300mm length live stakes along creek banks to promote stabilization and shade for fish species 10. Project Overheads — 43,913.00 Includes travel, mobilization, layout, supervision and material delivery Total (not incl. GST) - $979,089.28 270 Shoemaker Street • Kitchener, Ontario • N2E 3E1 • 519 748 6500. 748 6626 Items Not Included as Part of Contract - Conservation, municipal, provincial or federal permit/approval fees (if required). These costs would be billed at cost plus 5% administration. ($2,500.00 Allowance) - Any expenses associated with MBTW to plot, copy, or courier project drawings to respective approving agencies. These costs would be billed at cost plus 5% administration. - Travel by MBTW. This cost would be billed at $0.55 per km. - Any expenses to engage an independent agency to perform geo-technical review or compaction testing of excavations, granular base and asphalt paving as well as any concrete cylinder tests related to bridge abutment construction ($10,000.00 Allowance) - Locating, decommissioning or relocating any potential underground utilities located within work areas. Utility locates to be confirmed prior to works commencing. 270 Shoemaker Street • Kitchener, Ontario • N2E 3E1 • 519 748 6500. 748 6626